英文合同

时间:2023-10-18 11:14:52 合同范本 我要投稿

英文合同模板20篇

  随着法治精神地不断发扬,人们愈发重视合同,合同的用途越来越广泛,签订合同是为了保障双方的利益,避免不必要的争端。那么一份详细的合同要怎么写呢?下面是小编帮大家整理的英文合同20篇,供大家参考借鉴,希望可以帮助到有需要的朋友。

英文合同模板20篇

  英文合同1

  一.hereby

  英文释义:by means of , by reason of this

  中文译词:特此,因此,兹

  用法:常用于法律文件、合同、协议书等正式文件的开头语;在条款中需要强调时也可用。

  语法:一般置于主语后,紧邻主语.

  例1:

  The Employer hereby covenants to pay the Contractor in consideration of the execution and completion of the Works and the remedying of defects therein the Contract Price or such other sum as may become payable under the provisions of the Contract at the time and in the manner prescribed by the Contract.

  参考译文:

  业主特此立约保证在合同规定的期限内,按合同规定的方式向承包人支付合同价,或合同规定的其它应支付的款项,以作为本工程施工、竣工及修补工程中缺陷的报酬。

  注释:

  (1)hereby: by reason of this 特此

  (2)covenant: v. make a formal agreement 立约,签订合同、条约; n. legal agreement具有法律约束的正式合同

  (3)completion of the Works: 工程的竣工

  (4)therein: in the Works在本工程中

  (5)the Contract Price: 合同总价,指工程的总造价

  (6)such...as: 关系代词,相当于that, which

  (7)under: in accordance with 根据,按照

  (8)the provisions of the Contract: terms and conditions of the Contract合同条款

  例2:

  We hereby certify to the best of our knowledge that the foregoing statement is true and correct and all available information and data have been supplied herein, and that we agree to provide documentary proof upon your request.

  注释:

  (1)hereby:特此

  (2)to the best of our knowledge:as far as we know据我们所知

  (3)foregoing statement:above-mentioned statement上述声明

  (4)herein:in this, in the statement在声明中

  (5)documentary proof:证明文件

  参考译文:

  特此证明,据我们所知,上述声明内容真实,正确无误,并提供了全部现有的资料和数据,我们同意,应贵方要求出具证明文件。

  例3:

  This Contract is hereby made and concluded by and between Co. (hereinafter referred to as Party A) and Co. (hereinafter referred to as Party B) on (Date), in (Place), China, on the principle of equality and mutual benefit and through amicable consultation.

  注释:

  (1)hereby:特此

  (2)hereinafter referred to as Party A:以下称甲方

  (3)on the principle of equality and mutual benefit:在平等互利基础上

  (4)through amicable consultation:通过友好协商

  参考译文:

  本合同双方, 公司(以下称甲方)与 公司(以下称乙方),在平等互利基础上,通过友好协商,于 年 月 日在中国 (地点),特签订本合同。

  例4:

  This agreement is hereby made and entered into on (Date), by and between Co. China (hereinafter referred to as Party A) and Co. (hereinafter referred to as Party B).

  注释:

  (1)this agreement is hereby made and entered into:特此订立本协议 在法律文件中表示“订立本协议”可用以下4个动词:sign (make, conclude or enter into) this agreement, 按照同义词连用的写作特点,可用上述4个动词中的'两个来表示)。

  (2)hereinafter referred to as Party B:以下简称乙方

  参考译文:

  本协议特由中国 公司(以下简称甲方)与 公司(以下简称乙方)于 年 月 日订立。

  二 hereof

  英文释义: of this

  中文译词:关于此点;在本文件中

  用法:在表示上文已提及的“本合同的、本文件的??”时,使用该词。例如表示本合同条件、条款时,可以说“the terms, conditions and provisions hereof”,这里hereof表示“of this Contract”;又如表示本工程的任何部分,可用“any parts hereof”,这里hereof表示“of this Works”。 语法:一般置于要修饰的名词的后面,与之紧邻。

  hereof和thereof的区别:hereof强调“of this”。例如,上面的“the terms, conditions and provisions thereof”中的thereof表示of the Contract;“any parts thereof”中的thereof表示of the Works。

  例1

  Whether the custom of the Port is contrary to this Clause or not, the owner of the goods shall, without interruption, by day and night, including Sundays and holidays (if required by the carrier), supply and take

  delivery of the goods. Provided that the owner of the goods shall be liable for all losses or damages including demurrage incurred in default on the provisions hereof.

  注释:

  (1) Whether the custom of the Port is contrary to this Clause or not:不论港口习惯是否与本款规定相反,whether? or not:不论??是否

  (2) the owner of the goods:货方

  (3) without interruption:无间断地

  (4) carrier:承运人

  (5) in default on the provisions hereof:违反本款规定 hereof:of this Clause

  参考译文:

  不论港口习惯是否与本款规定相反,货方都应昼夜地,包括星期日和假日(如承运人需要),无间断地提供和提取货物。货方对违反本款规定所引起的所有损失或损坏,包括滞期应负担赔偿责任。

  例2

  Foreign trade dealers as mentioned in this Law shall, in accordance with the provisions hereof, cover such legal entities and other organization as are engaged in foreign trade dealings.

  注释:

  (1) foreign trade dealers:对外贸易经营者

  (2) as mentioned in this Law:本法所称

  (3) the provisions hereof:the provisions of this Law 本法规定

  (4) legal entity:法人

  (5) be engaged in foreign trade dealings:从事对外贸易经营活动 参考译文:

  本法所称对外贸易经营者,是指依照本法规定从事对外贸易经营活动的法人和其他组织。

  例3

  The establishment of a limited liability company or a company limited by shares shall comply with the conditions and provisions of this Law. A company complying with the conditions and provisions hereof may be registered as a limited liability company or a company limited by shares. Provided that if a company fails to comply with the conditions and provisions hereof, the company in question shall not be registered as a limited liability company or a company limited by shares.

  注释:

  (1)a limited liability company:有限责任公司

  (2)a company limited by shares:股份有限公司

  (3)provisions hereof:本法规定 hereof: of this Law

  (4)may be registered as:登记为

  参考译文:

  设立有限责任公司、股份有限公司,必须符合本法规定的条件。符合本法规定的条件的,登记为有限责任公司或者股份有限公司;不符合本法规定的条件的,不

  得登记为有限责任公司或股份有限公司。

  例4

  If, as a result of withdrawal or any other reasons, an arbitrator fails to perform his duties as an arbitrator, another arbitrator shall, in accordance with the provisions hereof, be selected or appointed. 注释:

  (1) as a result of withdrawal or any other reasons:回避或者其它原因

  (2) arbitrator:仲裁员

  (3) the provisions hereof:the provisions of this Law 本法规定

  (4) be selected or appointed:选定或指定

  参考译文:

  仲裁员因回避或者其它(转 载于:wWw.cnboThwiN.cOM 博 威范文 网:协议书英文怎么写)原因不能履行职责的,应当依照本法规定重新选定或指定仲裁员。

  例5

  In the event of conflict between the provisions on arbitration formulated and prepared prior to the effective date of this Law and the provisions of this Law, the provisions hereof shall prevail.

  注释:

  (1) conflict:相抵触

  (2) prior to the effective date of this Law:本法施行前

  (3) the provisions hereof shall prevail:以本法为准 hereof:of this Law 参考译文:

  本法施行前制定的有关仲裁的规定与本法的规定相抵触的,以本法为准。 例6

  Where, in accordance with laws, the circumstance(s) specified in Article 15 and Article 16 of this Law is /are confirmed, the organization with compensatory obligations shall pay compensation in any of the circumstance in question.

  Where the claimant for compensation demands the confirmation of one of the circumstances specified in Article 15 and Article 16 hereof, and the demanded organization refuses to make the confirmation, the claimant shall have the right to lodge a complaint. Where the claimant claims compensation, the claim, shall, first, be lodged to the organization for compensatory obligations.

  The provisions of Article 10, Article 11 and Article 12 hereof shall apply to/ in the procedures of compensation.

  注释:

  (1) the organization with compensatory obligations:赔偿义务机关

  (2) shall pay compensation:应当给予赔偿

  (3) the claimant for compensation:赔偿请求人

  (4) Article 15 and Article 16 hereof:本法第十五条、第十六条 hereof:of this Law

  (5) shall have the right to lodge a complaint:有权申诉

  (6) claims compensation:要求赔偿

  (7) apply to/ in:适用 More Examples: The comment applies equally here. /That argument does not apply in this case. /That applies to at least nine-tenths of the people we see about. /These remarks apply to every town in this kingdom. /The rules of safe driving apply to everyone. 参考译文:

  赔偿义务机关对依法确认有本法第十五条、第十六条规定的情形之一的,应当给予赔偿。

  赔偿请求人要求确认有本法第十五条、第十六条规定情形之一的,被要求的机关不予确认的,赔偿请求人有权申诉。赔偿请求人要求赔偿,应当先向赔偿义务机关提出。赔偿程序适用本法第十条、第十一条、第十二条的规定。

  例7

  If an arbitrator involved in one of circumstances specified in Item 4, Article 34 of this Law, and if it is serious, or those specified in Item 6, Article 58 hereof, the arbitrator in question shall, in accordance with the law, bear the legal liability and responsibility. The arbitration commission shall remove the name of the arbitrator in question from the list of arbitrators.

  注释:

  (1) arbitrator:仲裁员

  (2) Article 58 hereof:本法第五十八条 hereof:of this Law

  (3) bear the legal liability and responsibility:承担法律责任

  (4) the arbitration commission:仲裁委员会

  (5) remove the name of the arbitrator in question from the list of arbitrators:将其除名

  参考译文:

  仲裁员有本法第三十四条第四项规定的情形,情节严重的,或者有本法第五十八条第六项规定的情形的,应当依法承担法律责任,仲裁委员会应当将其除名。 例8

  If, pursuant to this Law, the relevant responsible authorities with the duty of approvals fail to grant approval to such an application as meets the requirements and provisions hereof, or the company registration authorities fail to register a company whose application meets the requirements hereof, the party in question may, in accordance with laws, apply for reconsideration or bring an administrative suit.

  注释:

  (1) the relevant responsible authorities with the duty of approvals:履行审批职责的有关主管部门

  (2) meets the requirements and provisions hereof:符合本法条件

  (3) the company registration authorities:负责公司登记的主管部门

  (4) the requirements hereof:本法条件 hereof: of this Law

  (5) apply for reconsideration:申请复议

  (6) bring an administrative suit:提起行政诉讼

  英文合同2

  一、出租人: (“甲方”)

  landlord: (part a )

  二、承租人: (“乙方”)

  tenant: (part b )

  三、租赁范围及用途:

  tenancy:

  3.1 甲方同意将其所有的位于_________________________________________的房屋在良好及可租赁的状态下租给乙方为居住使用。

  party a hereby agrees to lease its property located at

  ___________________________________in good and tenantable condition to party b for residential use.

  3.2 乙方应将出租房屋用作住宅用房。

  the leased property shall be used by part b for residential purpose.

  四、租赁期:

  term of tenancy:

  4.1 租赁期为_____年,自 年 月____日起至_______年____月____日止。

  the tenancy shall be for a term of years,commencing on ______________and expiring on __________________.

  4.2 租赁期满,如乙方不再根据此条款续约,甲方有权收回全部出租房屋,乙方应如

  期交换出租房屋予甲方。乙方如要求续租,须在本合同期满三个月前向甲方提出书面申请,再由双方另行续租事宜。

  on expiry of the tenancy, if party b has not exercised its option to renew this agreement in accordance with this clause,party a has the right to repossess the entire leased property,and party b shall deliver the leased property to the party a provided always that party b shall have the option to renew this agreement upon giving prior written novice to party a of its intention to do so that least three(3) months before the expiration of this agreement.

  五、租金:

  rent

  5.1 双方谈定的租金为每月____________________人民币,租金包括除水、电、液化气、电话费以外的一切管理费。

  the rent for the leased property as agreed to by both parties is rmb___________yuan per month, which rent includes all management fee.

  5.2 支付甲方壹个月的租金,应在每个月的第十天以前支付给甲方。

  party b pay the rental fee before the tenth day of every calendar one month.

  5.3 所有保证金、租金等费用均以人民币通过银行汇入甲方所提供的以下银行账户及户名:

  账号:____________________户名:______________开户行:____________________

  all payments of security deposit,rent fee,etc heteunder shall be made be made by bank transfer rmb to party as following account.

  account no:________________________,user name:_____________bank:___ ________ __

  六、保证金:

  security deposit:

  6.1 为确保出租房屋及其设施之安全并完好及租赁期内相关费用之如期结算,乙方同意于签订合同10天内支付给甲方贰个月租金的租赁押金计__________________人民币作为乙方确保合同履行之保证金。乙方搬入后十天内付壹个与租金计______________人民币。

  to ensure the protection and good condition of the leased property and the related facilities as well as the prompt payment and settlement of all related charges during the term of tenancy,party b agrees to pay to party a with 10 days when the execution of this agreement a security for party b’s obligations hereunder. when party b move in,party b pay one month’s rental in the amount of___________with 10days.

  6.2 除合同另有约定之外,甲方应于租赁期满或此合同提前终止之期且乙方透空、点清并付清所有应付费用后,当天将保证金全额无息退还乙方,如保证金以人民币支付,届时也应以人民币形式退还。

  unless otherwise provided in this agreement, party a shall return to party b the entire security deposit without interest thereon upon expiration or soonder detemination of this agreement provide that party b has vzcated the leased property and settled all related charges. if this security deposit was paid in rmb,it shall be returned to party b in the form of rmb.

  七、其他费用:

  other charges:

  乙方应承担租赁期内实际使用而产生的水、电、液化气费、电话费并按单自行如期交纳所属管理公司或有关机构。

  during the term of tenancy,party b is responsible for paying the charges in relation to water, electricity, gas,telephone charges on the basis of the amount of such utilities party b uses. such charges shall be paid when due according to the invoice therefore received by party b from the management company or relevant authority every month.

  八、甲方的`责任:

  party a’s obligations:

  8.1 甲方须按时将出租房屋及其家私家具用品与其设施以良好状态交付乙方使用。

  party a shall deliver on schedule to party bvacant possession of the leased property including the furniture,furnishing and appliances and the related facilities for party b’s use(furniture,furnishing and appliances to be detailed in appendisl.)

  8.2 租赁期内甲方不得收回出租房屋(除非本合同另有规定),甲方保证乙方可不受干扰的享用该物业。

  party a shall not repossess the leased property during the term of party a disturb of interfere with party b’s quiet enjoyment of the leased property.

  8.3 在乙方遵守本合同的条款及支付租金的前提下,乙方有权于租赁期内拒绝甲方或其他人骚扰而安静享用出租房屋。

  proviede that party b pays the rent and performs and observes party b’s terms and conditions in accordavce with this agreement, party b shall be entitled to hold and enjoy the leased property throughout the term of this tenancy without any interruption by party a or any other person.

  8.4 租赁期内出租房屋的结构,进出物业的排水、上下管道、电路等处于良好使用状态。

  party a agrees to repair and maintain the structure,drains, pipes and cables, etc.leading in to or from the leased property at all times in good and tenable repair during the term of this tenancy.

  九、乙方的责任:

  party b’s obligations:

  9.1 乙方应按合同的规定,按时支付租金,保证金及其他各项应付费用。

  party b shall promptly pay all rent ,security deposit and other charges payable by it in accordance with the terms of this agreement.

  9.2 乙方应爱护使用出租房屋,如因乙方的过失或过错致使房屋设施及屋内用具和饰品受到损坏(正常损耗除外),乙方应负赔偿责任。

  paryt b shall treat the leased property with care. if as a result of party b’s negligence or misconduct, the leased property and the related facilities and accessorties suffer any damage(fair wear and tear excepted ),party b shall be responsible for compensating party a for such damages.

  9.3 乙方应按本合同的约定合法使用出租房屋,不得擅自改变使用性质,不应存放中华人民共和国法律下所禁止的危险物品,如因此发生损害,乙方应承担全部责任。

  party b shall use the leased property legally as agreed in this agreement and may not change such use on its own…party b shall not store any dangerous items which are prohibited by the laws in the people’s republic of china in the leased property and shall be fully responsible for any admages of losses as result thereof.

  9.4 未经甲方事先书面同意,乙方不得将出租房屋转租或租给其他的第三者。

  without party a’s prior written consent ,party b may not assign the tenancy or sublet the leased property to a third party.

  十、违约处理:

  breach of agreement :

  10.1 甲、乙任何一方如未按本合同的条款履行,构成违约,应承担相应的违约责任。双方同意违约方应赔偿守约方之直接损失人民币____________元。

  if either party a or party b fails to perform its obligations hereunder ,it shall constitute a breach of this agreement and the defaulting party shall be liable for the liabilities resulting from such breach. the parties agree that the party in breach shall pay the other party compensation ____________________for the direct loss and damage suffered by the other party as result of such breach .

  10.2 乙方有下列行为之一的,甲方有权终止本合同,收回出租房屋,并且保证金不予返还;

  party a shall have the right to terminage this agreement ,repossess the leased property and forfeit the security deposit if party b commits one of the following:

  a.未得甲方书面书面同意,将出租房屋擅自转租;

  sublets the leased property without party a’s written consent;

  b.未得甲方同意将出租房擅自拆改结构或改变用途的:

  alters the structure of the leased property or uses the leased property other than for the purpose started herein without party a’s consent;

  c.无故拖欠租金超过三天(除双方就本合同存在争议除外)。

  fails to pay rent without any reason for more than thirty (30)days after the due date except where there is a dispute in respect of this agreement.

  十一、适用法律:

  applicable law:

  本合同的成立,其有效性、结实、签署和解决与其他有关的一切纠纷均应受中国法律的管辖并依据中国法律解释。

  the formation of this agreement ,its validity,interpretation,executiong and settlement of any disputes arising hereunder shall be governed by and construed in accordance with the laws of the people’s republic of china.

  十二、争议的解决:

  dispute resolution:

  凡因执行本合同所产生的或与本合同有关的一切争议,双方应通过友好协商解决;协商不成,应提交中国国际经济贸易仲裁委员会,按其仲裁规则和中华人民共和国仲裁法进行仲裁。仲裁解决是终局的,对双方都有约束力。

  in the case of disputes arising over this agreement of any matters related hereto ,the parties shall negotiate in good faith to resolve such disputes.if such negotiation fails, the parties shall submit the dispute to arbitration by the china international economic and trade arbitration commission in accordance with its arbitration rules and the arbitration law of the people’s republic of china.the decision of the arbitration body is final and shall be binding on the parties hereto.

  十三、其他

  others:

  13.1 本合同如有未尽事宜,由甲、乙双方洽谈解决。

  if this agreement it unclear with respect to certain matters, the two parties shall discuss to resolve such ambiguities.

  13.2 本合同由中、英文写成,两种文本具有同等效力。

  this agreement is written both in the chinese and english languages.both versions shall be equally authentic.

  13.3 本合同经双方签字后立即生效,未经双方同意,不得任意终止或修改,本合同另有约定除外,本合同一式二份,甲、乙双方各执一份。

  this agreement shall become effective upon the signing thereof by the parties hereto an registration with the relevant authorities.save and except as provided in this agreement ,this agreement may not bye terminated or amended without the consent of both parties.there are two(2) originals of this agreement ,one for party a,one for party b.

  本合同于__________年 月_____日签订。

  this agreement was signed in __________________on ________________

  甲方: 乙方:

  partya: partyb:

  盖章: 盖章:

  seal: seal:

  地址: 地址:

  address: address:

  电话: 电话:

  telephone number: telephone number:

  传真: 传真:

  fax number: fax number:

  英文合同3

  出租人(甲方)Lessor (hereinafter referred to as Party A) :

  承租人(乙方)Lessee (hereinafter referred to as Party B) :

  根据国家有关法律、法规和有关规定,甲乙双方在平等自愿的基础上,经友好协商,就甲方将其合法

  拥有的房屋出租给乙方使用,乙方承租使用甲方房屋事宜,订立本合同。In accordance with relevant Chinese laws, decrees and pertinent rules and regulations, Party A and Party B have

  reached an agreement through friendly consultation to conclude the following contract.

  一、物业 Property:

  甲方同意将其所有的位于上海市_ 房屋及其设施在良好及可租赁的状态

  下租给乙方居住使用,产权证号为:,出租房的建筑面积总计 平方米。in Shanghai and the

  related facilities in good and tenantable condition to Party B for residential use, property right

  number, the size of leased property is 2

  二、租赁期 Term of Tenancy:

  1. 租赁期为自年日。甲方应于月日前将

  房屋腾空并交付乙方使用。 )and

  (year). Party A will clear the property and provide it to (year).

  2. 租赁期满,甲方有权收回全部出租房屋,乙方应如期交还。乙方需继续承租该房屋的,则应于租赁期满前一个月,向甲方提出续租书面要求,经甲方同意后签订新的租赁合同。 On expiry of the tenancy, Party A has the right to take back the entire leased property and Party B shall deliver the leased property to Party A. Party B shall apply for extension in writing to Party A one months before the expiration if Party B intends to continue the lease, the new lease contract shall be signed after getting Party A’s approval.

  三、租金 Rental:

  1.双方议定租金为每月人民币元整(¥)包括房屋的物业管理费,包括(不包括)发票费用。 ¥ including property management fee, including (excluding) invoice fee.

  2. 租金按个月为壹期支付;第一期租金于年月日以前付清;以后每期租金于每个付款月的第 日以前缴纳,先付后住(若乙方以汇款形式支付租金,汇费由汇出方承担)。甲方收到租金后予以书面签收。

  day each paying month. Party B will pay the rental before using the property and attached facilities (In case Party B pays the rental in the form of remittance, the date of remitting will be the day of payment and the remittance fee will be borne by the remitter.) Party A will issue a written receipt after receiving the payment.

  3. 如乙方逾期支付租金超过十天,则每天以月租金的0.5%支付滞纳金;如乙方逾期支付租金超过十五天,则视为乙方自动退租,构成违约,甲方有权收回房屋,并追究乙方违约责任。 In case the rental is more than ten days overdue, Party B will pay 0.5% of monthly rental as overdue fine every day; if the rental is paid 15 days overdue, Party B will be deemed to have withdrawn from the property and breach the contract. In this situation, Party A has the right to take back the property and take actions against Party B’s breach.

  四、保证金 Security Deposit:

  1. 为确保出租房屋及其设施之安全与完好及租赁期内相关费用之如期结算,乙方同意于年月___ 日前支付给甲方保证金人民币 元整(¥___ ),甲方在收到保证金后予以书面签收。To ensure the welfare and good condition of the leased property and attached facilities as well as the prompt payment and settlement of all related charges during the term of the tenancy, Party B agrees to pay Party A¥(year).Party A will issue a written receipt after receiving the deposit.

  2. 除合同另有约定之外,甲方应于租赁期满或此合同提前终止之日,且双方确认交房方迁空、清点,当天将保证金全额无息退还乙方,在甲方退还保证金之前,乙方有权保留房屋钥匙。 Unless otherwise provided in this Agreement, Party A shall return to Party B the entire security deposit without interest thereon upon expiration of the tenancy or sooner termination of this Agreement, and at the time when both parties have confirmed the return of the premises. Party B has the right to retain the keys to the premises until Party A returns the deposit.

  3. 甲方因乙方违反本合同的规定而受的损失,可在保证金中扣抵双方协议数目,不足部分乙方必须在接到甲方付款通知后十天内补足。Party A may deduct a negotiated amount of security deposit towards Payments of any actual damages Party A shall have incurred or suffered as a result of Party B’s breach of this Agreement. In case the security deposit is not sufficient to cover such amounts, Party B must pay the deficient within 10 days of the receipt of a demand from Party A.

  五、甲方的义务Obligations of Party A:

  1. 甲方须按时将出租房屋以良好状态交付乙方使用。

  Party A shall deliver on schedule to Party B the leased property for Party B’s use.

  2. 租赁期内甲方不得无故收回出租房屋。(除非本合同另有规定)

  Party A shall not take back the leased property, without cause, during the term of the tenancy.(unless otherwise stipulated in this Agreement)

  3. 在乙方遵守本合同的条款及交付租金的前提下,如非中国法律特别规定,乙方有权于租赁期内拒绝甲方或其他人骚扰而安静享用出租房屋。

  Provided Party B paying the rent and performing and observing Party B’s terms and conditions herein contain shall peaceably hold and enjoy the leased property throughout the term of this Agreement without any interruption by Party A or any other person save and except as required by the law of the People’s Republic of China.

  4. 房屋基本设施和结构(不包括乙方损坏的家私和器具)损坏时,甲方有修缮的责任并承担有关的费用,并对其作定期修保。

  Party A is responsible for repairing and maintaining the basic facilities (excluding furniture and appliances damaged by Party B), the structure of the leased property and for bearing all costs related thereto.

  5. 甲方谨在此声明及保证甲方为出租房屋的合法拥有人并有合法地位出租此房屋予乙方。就本合同及出租此房屋予以乙方之事,甲方已取得所有有关机构的.批准,包括政府批准及抵押权人的同意(如适用)。甲方于本合同所做出的声明及保证,如有错误或违反者,甲方须就乙方因此而引致的任何损失、损害、支出及费用做出全部补偿。 Party A hereby represents and warrants that Party A is legal owner of the leased property and has the necessary legal capacity to lease the property to Party B. Party A has also obtained all the necessary authorizations from all relevant authorities in the People’s Republic of China in respect of this Agreement and the leasing of the property to Party B, including government approval and/or mortgagee consent (if applicable).

  Party A shall be liable to Keep Party B be fully indemnified against any costs, expenses, losses and damages incurred to suffered by Party B as a result of any breach of Party A’s representations of warranties herein(including but not limited to legal costs.

  6. 如在租赁期内,租赁房屋发生所有权全部或部分转移、和其他影响乙方权益的事情时,甲方应保证所有权人或其他影响乙方权益的第三者,能继续遵守本合同所有条款。如乙方于本合同下的权益受此等所有权人或第三者所影响或损害,甲方须负责补偿乙方的所有损失、损害、支出及费用。

  If during the term of the tenancy, all or part of the leased property is transferred of Party B’s right to use leased property is affected, Party A shall ensure that such transferee or third party having an effect on Party B’s right to use the leased property will continue to abide by the terms of this Agreement. Party A shall also be liable to keep Party B be fully any of Party B’s interests herein are affected or prejudiced by such transferee or third party.

  六、乙方的责任 Obligations of Party B:

  1. 乙方应按合同的规定,按时支付租金,保证金及其它各项应付费用如水、电、煤、宽带等费用。 Party B shall promptly pay all rent, security deposit and other charges such as water, electricity, gas, ADSL, etc payable by it in accordance with the terms of this Agreement.

  2. 乙方经甲方事先书面同意,可在承租用房内进行装修及添置设备。租赁期满后恢复原状或可正常出租状态(正常损耗除外),并承担其费用,经甲方验收认可后归还甲方。乙方在租赁结束交房时应保持房屋清洁。

  Party B may, with the prior written consent of Party A, renovate and install additional facilities in the leased property. Upon expiry of the tenancy, the leased property shall be returned to Patty A in its original conditions of normal lease conditions(fair wear and tear excepted), and all expenses arising there from shall be borne by Party B. Party B shall keep the premise clean once returning it to Party A.

  3. 乙方应爱护使用租赁的房屋,如因乙方的过失或过错致使房屋及设施受到损坏(正常损耗除外),乙方应负赔偿责任。 Party B shall treat the leased property with care. If, as a result of party B’s negligence or misconduct, the leased property and the related facilities suffer any damage (fair wear and tear exempt), Party B shall be responsible for compensating Party A for such damages.

  4. 乙方应按本合同的约定合法使用租赁房屋,不得擅自改变使用性质,不应存放中华人民共和国法律下所禁止的危险的物品,如因此发生损害,乙方应承担全部责任。Party B shall use the leased property legally as agreed in this Agreement and may not change such use on its own. Party B shall not store any dangerous items which are prohibited by the laws in the People’s Republic of China in the leased property and shall be fully responsible for any damages or losses as a result thereof.

  5. 未经甲方事先书面同意,乙方不得将承租的房屋转租或分租给其他的第三方.

  Without Party A’s prior written consent, Party B may not assign the tenancy or sublet the leased property to a third party.

  七、违约处理Breach of Agreement:

  1. 甲、乙任何一方在未征得对方谅解的情况下,不履行本合同规定条款,导致本合同中途中止,则视为该方违约,双方同意违约金为人民币元整(¥ ),若违约金不足弥补无过错方之损失,则违约方还需就不足部分支付赔偿金。 During the lease term, any party who fails to fulfill any article of this contract without the other party’s (¥party in breach should pay additional compensation to the other party.

  2.乙方有下列行为之一的,甲方有权终止本合同,收回出租房屋,并且保证金不予退还。

  Party A shall have the right to terminate this Agreement, re-possess the leased property and forfeit the security deposit if Party B commits one of the following:

  a) 将承租的房屋擅自转租

  Sublets the leased property to another person

  b) 未得甲方同意将承租的房屋擅自拆改结构或改变用途的

  Alters the structure of the leased property without authorization or uses the leased property rather than for the purpose stated herein

  c) 无故拖欠租金超过十五天

  Fails s to pay rent without any reason for more than 15 days after the due date

  八、不可抗力 Force Majeure:

  若由于不可抗拒的自然灾害(包括但不限于火灾、洪水、地震、施工、敌对、瘟疫等行为等)

  获其他非乙方过错所造成的对本物业的损毁致其无法居住或使用本物业,乙方有权终止本组契约,甲方

  必须全数退还乙方所有保证金和当月所余租期之相应租金。 If the leased property is destroyed, damaged and rendered uninhabitable of unusable due to force major

  (include, but not limited to, fires, flood, earth quakes, accidents, strikes, wars, insurrections, public enemy,pestilence etc).or actions that are not the result of Party B’s fault, Party B shall have the right to terminate this Agreement and prorated balance of all rents and management fees paid, as well as security deposit, shall be returned to Party B without any set-offs or deductions.

  九、适用法律Applicable Law:

  本合同的成立,其有效性,解释,签署和解决与其有关的一切纠纷均应受中国法律的管辖并依据中国法律解释。The formation of this Agreement, its validity, interpretation, execution and settlement of any disputes arising hereunder shall be governed by and construed in accordance with the laws of the People’s Republic of China.

  十、争议的解决 Dispute Resolution:

  凡因执行合同所产生的或与本合同有关的一切争议,双方应通过友好协商解决;协商不成,应提交上海仲裁委员会,按其仲裁规则和中华人民共和国仲裁法在上海进行仲裁, 仲裁裁决是终局的,对双方都有约束力。In the case of disputes arising over this Agreement or any matters related hereto, the parties shall negotiate in good faith to arbitration by Shanghai Arbitration Commission in Shanghai accordance with its arbitration rules .The decision of the arbitrage body is final and shall be binding on the parties hereto.

  十一、其他 Others:

  1. 本合同附件是本合同不可分割的组成部分,具有同等法律效力。

  The attachment to this Agreement is an inseparable part of this Agreement and is equally enforceable.

  2. 本合同如有未尽事宜,由甲、乙双方洽谈解决。

  If this Agreement is unclear with respect to certain matters, the two parties shall discuss to resolve such ambiguities.

  3. 本合同由中文和英文写成,以中文版本为准,英文仅供参考。

  This Agreement is written both in the Chinese and English languages. Only Chinese versions shall be authentic, English version is for reference.

  4. 本合同自签字之日起生效。未经双方同意,不得任意终止或修改(本合同另有约定除外)本合同一式

  三份,甲、乙双方各执一份,中介执一份。This Agreement shall become effective upon the signing thereof by the parties hereto. Save and except as

  provided in this Agreement, this Agreement may not be terminated or amended without the consent of both parties. There are three originals of this Agreement, one for each party and agency hold one.

  5. 双方须各自分担因准备,商讨及签署本合同所引致法律费用。

  Each party shall bear its own legal costs in relation to the preparation negotiation and execution of this Agreement.

  ______________________________________________________________________________________

  ______________________________________________________________________________________

  ______________________________________________________________________________________

  ______________________________________________________________________________________

  甲方(Party A):乙方(Party B):

  身份证(ID): 护照号(Passport):

  电话(Telephone): 电话(Telephone)::

  地址(Address):

  中介方(Agency):

  电话(Telephone):

  英文合同4

  DATE :C/NO :

  Inv. No:

  PART A:

  PART B:

  BOTH OF THE 2 COMPANIES ( PART A AND PART B) AGREED

  TO PAY THE COMMISSION FOR THE BUSINESS BETWEEN THEM AS FOLLOWS:

  1. BUSINESS ITEMS:

  PRODUCTS:FABRIC

  QUANTITY:76000M(CONTRACT)

  PRICE:FOB USD7.45/M ECT.

  AMOUNT: USD593,500.00(CONTRACT)

  AMOUNT: USD531,622.55(ACTUALLY)

  2. COMMISSION ITEMS:

  COMMISSION: FOR THE TOTAL AMOUNT .

  COMMISSION AMOUNT: USD21,124.70

  3. PAYMENT ITEMS:

  PART A SHOULD PAY THE COMMISSION BY T/T .

  Confirmed By:

  PART A: PART B:

  DATE :C/NO :

  Inv. No:

  PART A:

  PART B:

  BOTH OF THE 2 COMPANIES ( PART A AND PART B) AGREED TO PAY THE COMMISSION FOR THE BUSINESS BETWEEN THEM AS FOLLOWS:

  3. BUSINESS ITEMS:

  PRODUCTS:MEN’S SUITS

  QUANTITY:2877UNDS

  PRICE:FOB EUR40.60/UNIT

  AMOUNT: EURO116,806.20

  4. COMMISSION ITEMS:

  COMMISSION: FOR THE TOTAL AMOUNT .

  COMMISSION AMOUNT: USD5700.00

  3. PAYMENT ITEMS:

  PART A SHOULD PAY THE COMMISSION BY T/T .

  Confirmed By:

  PART A: PART B:

  英文合同5

  THIS AGREEMENT OF LEASE is made on this 16th day of December 20xx by and BETWEEN:-

  Mrs. Ghazala Waheed w/o Abdul Waheed, Adult, R/o House No.***-*, DHA, Lahore Cantt, (hereinafter to as the LESSOR of the ONE PART).

  And

  Mr.* ***,R/o China, refereed to as the LESSEE of the OTHER PART.(Expression “LESSOR” and “LESSEE” wherever the context so permit shall always mean and include their respective heirs, successors legal representative and assignees).

  WHEREAS the LESSOR is the lawful owner and in lawful possession of House No,***-*,DHA, Lahore Cantt, consisting of 4 Bedrooms with bath, D/D,TV; Lounge, Kitchen, Store, Servant, Quarter together with fixtures and fitting (hereinafter collectively called the DEMISED PREMISES).

  AND WHEREAS the LESSOR has agreed the lease and the LESSEE has agreed to take on lease the DEMISED PREMISES on the terms and condition as given below:-

  1. This agreement in only valid if LESSEE is renewed and extended for the lease period.

  2. The LESSOR lets LESSEE takes the DEMISSED PREMISES for a period of 12 months

  Commencing from 15th January 20xx. The Lease is renewable for a further period as may be mutually agreed in writing on expiry of the lease period

  3. The rent of the DEMISED PREMISES shall be USD3,300/-(US dollars Three Thousand and Three hundred Only) per month

  4. The LESSOR hereby acknowledges receipt of the sum of USD.19,800/-(US dollars Nineteen Thousand and eight Hundred Only) per month.

  5. It is hereby agreed between the parties that the LESSEE shall pay the aforesaid monthly rent USD. 3,300/-(US dollars Three Thousand and Three hundred Only) as the monthly rental advance by 20th of each calendar month for which if is due after completion of advance rent period ending on 15th July 20xx.

  6. That the LESSOR hereby acknowledges receipt of the (来自:www.zaidian.cOm 在 点 网)sum of Rs.60,000/-(Rupees Sixty Thousand Only) from the LESSEE as FIXED EDPOSIT SECURITY which shall be refunded to the LESSEE on giving back the vacant possession of the DEMISED PREMISES after deduction of damages/shortages outstanding bills for Electricity, Water, Gas and Telephone charges etc, against the DEMISED PREMISES.

  THE LESSEE HERBY CONVENANTS WITH LESSOR AS FOLLOWING:

  1. To pay to the LESSOR the rent hereby reserved in the manner before mentioned.

  2. That the LESSEE shall not at any time during the terms, without the consent in writing of the LESSOR, pull down, damages or make any structure alterations to the DEMISED PREMESES provided always, the LESSEE shall have go write install any fixtures and fittings excluding air-conditioners in the DEMISED PREMESES, to detach and repossess the same s

  ubject to the restoration of the DEMISED PREMESES to their original state at his cost (reasonable wear and tear excepted) on the expiry of this lease or any renewal hereof.

  3. To use the DEMISES PREMISES for residential purpose and would not be used for a commercial purpose the DEMISES PREMISE would not be used occupied by Mr. **** And family.

  4. Not to sublet the whole or any part of the premises.

  5. To pay regularly the bills for Electricity, Gas, Water and Telephone charges in respect of the DEMISED PREMISES. A copy of all the paid utility bill be forwarded to the LESSOR every three month regularly. In case of disconnection of any facility due to non-payment, LESSEE will be responsible to get them restored and pay the same. All dues must be cleared before the expiry of the LEASE.

  6. The LESSEE shall keep and maintain the said premises in good and tenantable conditions during the tenure of the lease.

  THE LESSOR HEREBY CONVENANTS WITH THE LESSEE AS FOLLOWING:-

  1. To pay all existing and future rate, taxes assessments and other charges of a public nature whether impose by the Municipality, Government or any other authority in respect of DEMISED PREMISES.

  2. Not to erect or set up a building or structure on the DEMISES PREMISES nor to add to any existing building or structure during the period of lease or any renewal without the written consent of the LESSEE.

  IT IS HEREBY DECLEAR AND MUTURALLY AGREED BETWEEN THE LESSOR AND LESSEE ANS FOLLWING:=

  1. The LESSEE and the LESSOR shall have the right and option to terminate this Lease at any time only after the expiry of the lease period i.e., 24 months, provided they give ONE (1) month notice in advance to either of the parties.

  2. The meter reading of various utilities are as given below:-

  UTILITY METER NUMBER TODAY’S READING

  a) ELECRICITY ———————— ————————

  b) GAS ———————— ————————

  c) TELEPHONE ———————— ————————

  d) WATER ———————— ————————

  3. That the LESSEE has also agreed with the LESSOR for a mandatory increase in rent by 10% per annum, the rent would be enhanced to Rs.36,300/-( Rupees Thirty Six Thousand and Three

  Hundred Only), should the LESSOR and I ESSEE mutually to renew the Lease. It can be negotiated between the parties.

  WHEREOF THE PARTIES hereto have executed these presents on the and day above written.

  LESSSOR:__________________________

  Mrs. Ghazala waheed

  NIC NO._______________________

  LESSEE__________________________

  Mr.****

  Chinese passport no.___________________

  英文合同6

  买 方: (The ;Buyers)

  卖方: (The Sellers)

  兹经买卖双方同意按照以下条款由买方购进,卖方售出以下商品:

  This contract is made by and between the Buyers and the Sellers; whereby the Buyers agree to buy and the Sellers agree to sell the under-mentioned goods subject to the terms and conditions as stipulated hereinafter:

  (1) 商品名称:

  Name of Commodity:

  (2) 数 量: Quantity:

  (3) 单 价: Unit price:

  (4) 总 值: Total Value:

  (5) 包 装: Packing:

  (6) 生产国别: Country of Origin :

  (7) 支付条款: Terms of Payment:

  (8) 保 险: insurance:

  (9) 装运期限: Time of Shipment:

  (10) 起 运 港: Port of Lading:

  (11) 目 的 港: Port of Destination:

  (12)索赔:在货到目的口岸45天内如发现货物品质,规格和数量与合同不附,除属保险公司或船方责任外,买方有权凭中国商检出具的检验证书或有关文件向卖方索赔换货或赔款。

  Claims:

  Within 45 days after the arrival of the goods at the destination, should the quality, Specifications or quantity be found not in conformity with the stipulations of the contract except those claims for which the insurance company or the owners of the vessel are liable, the Buyers shall, have the right on the strength of the inspection certificate issued by the C.C.I.C and the relative documents to claim for compensation to the Sellers

  (13)不可抗力:由于人力不可抗力的原由发生在制造,装载或运输的过程中导致卖方延期交货或不能交货者,卖方可免除责任,在不可抗力发生后,卖方须立即电告买方及在14天内以空邮方式向买方提供事故发生的证明文件,在上述情况下,卖方仍须负责采取措施尽快发货。

  Force Majeure :

  The sellers shall not be held responsible for the delay in shipment or non-deli-very of the goods due to Force Majeure, which might occur during the process of manufacturing or in the course of loading or transit. The sellers shall advise the Buyers immediately of the occurrence mentioned above the within fourteen days there after . the Sellers shall send by airmail to the Buyers for their acceptancea certificate of the accident. Under such circumstances the Sellers, however, are still under the obligation to take all necessary measures to hasten the deliveryof the goods.

  (14)仲裁:凡有关执行合同所发生的一切争议应通过友好协商解决,如协商不能解决,则将分歧提交中国国际贸易促进委员会按有关仲裁程序进行仲裁,仲裁将是终局的,双方均受其约束,仲裁费用由败诉方承担。

  Arbitration :

  All disputes in connection with the execution of this Contract shall be settled friendly through negotiation. in case no settlement can be reached, the case then may be submitted for arbitration to the Arbitration Commission of the China Council for the Promotion of International Trade in accordance with the Provisional Rules of Procedure promulgated by the said Arbitration Commission . the Arbitration committee shall be final and binding upon both parties. and the Arbitration fee shall be borne by the losing parties.

  买方: 卖方:

  (授权签字) (授权签字)

  【拓展延伸】

  1.前言 Preamble

  一份标准英文合同通常可以分为前言(Preamble)、正文(Operative part)、附录(Schedule)及证明部分即结束词(Attestation)四大部分组成。

  前言(Preamble)由“Parties”及“Recitals”两部分组成。

  “Parties”为必备条款,在很多时候称为“commencement”即合同的开场白,主要介绍合同各方的名称或姓名、注册地及地址、邮编及在合同中的简称。当然,并不是所有的合同都要详细介绍以上诸要素,在许多简单合同中,只是提一下各方的名称。

  I. 以下为“Parties”的常用表达方式:

  1. This Agreement is entered into by and between ____ and ____.

  本协议由以下双方____和___ 签署。

  2. This Agreement is entered into by and between ____ (hereinafter referred to as____) and ____ (hereinafter referred to as "_____"), whereby it is agreed as follows:

  本协议由以下双方____(以下简称____)和_____(以下简称___)签署,达成如下协议:

  注:在很多合同中,这部分加入签约事由,如:

  This Agreement is entered into through friendly negotiations between _____ Co.

  (hereinafter referred to as the “Party A”) and _____ Co. (hereinafter referred to as the “Party B”) based on equality and mutual benefit to develop business on the terms and conditions set forth below:

  本协议由_____(以下称为甲方)和____(以下称为乙方)为发展业务在平等互利的基础上签订,其条款如下:

  This Agreement is entered into between _____ (hereinafter referred to as "Company"), and ______, (hereinafter referred to as "Employee") pursuant to paragraph VIII(2) of the Employee Handbook, whereby it is agreed as follows:

  本“协议”由_____(以下简称“公司”)与_____(以下简称“雇员”)根据“雇员手册”第VIII(2)款签署,“协议”内容如下:

  II. 以下为标准的“Parties”条款:

  3. This Agreement is made and entered into this _____th day of _____ in the year of ____ by and between ______, a company duly organized and existing under and by virtue of the laws of ______, with its principal place of business at _____ (hereinafter referred to as “_____”), and ______, a company duly organized and existing under and by virtue of the laws of _____, with its principal place of business at _____ (hereinafter referred to as “_____”), whereby it is agreed as follows:

  本合约由______,在_____法律之下并凭该等法律正式组织并存在的公司,其主要营业地点在______(下称_____),与_____,在_____法律之下并凭该等法律正式组织并存在的公司,其主要营业地点______(下称代理人),于_____日签订和缔结,协议如下:

  III. “Recitals” 由数个以"Whereas"字样开头的句子所组合而成(这些句子俗称为“Whereas Clauses”),表示当事人乃是在基于对这些事实(例如订约的目的、背景来由等)的共同认识,订立此合约。

  4. This Agreement is made and entered into this _____ day of _____ in the year of ____ by and between _______, a company duly organized and existing under and by virtue of the laws of ______, with its principal place of business at ______ (hereinafter referred to as “_____”), and ______, a company duly organized and existing under and by virtue of the laws of ______, with its principal place of business at ______ (hereinafter referred

  to as “_____”)

  WITNESSED

  WHEREAS, NOW THEREFORE, the parties hereto agree as follows:

  本合约由_____,在_____法律之下并凭该等法律正式组织并存在的公司,其主要营业地点在______(下称_____)(或下称供应商),与_______,在_____法律之下并凭该等法律正式组织并存在的公司,其主要营业地点_

  鉴于

  因此,双方当事人达成以下协议:

  注:WITNESSED可以用WITHNESSTH、WITHNESSTH THAT等来代替。

  IV. 在很多美国常用合同中,在很多情况下直接用RECITALS引导数个陈述语句或“Whereas Clauses”。下面为一个资产购买协议实例:

  This ASSET PURCHASE AGREEMENT (the "Agreement") is made and entered into as of May 19, 1997 by and among AAA, a Delaware corporation ("AAA"), BBB, a Delaware corporation and wholly-owned subsidiary of AAA ("Buyer"), CCC ("Summit"), and DDD, an Oregon corporation and wholly-owned subsidiary of Summit ("Seller").

  RECITALS

  A. The Boards of Directors of each of Summit, Seller, AAA and Buyer believe it is in the best interests of each company and their respective security holders that Buyer acquire certain listed assets and assume certain listed liabilities of Seller (the "Acquisition").

  B. On the date hereof, Buyer has executed a $2,000,000 irrevocable purchase order to purchase 400 time-based licenses for Summits Visual HDL interfaces for Visual Test bench ("VTB") software on AAAs standard form of purchase order, which is payable within five (5) business days after the date hereof.

  NOW, THEREFORE, in consideration of the covenants, promises and representations set forth herein, and for other good and valuable consideration, the parties agree as follows:

  2. 定义 Definition

  在正文(Habendum)部分,通常第一章为定义(Definitions)部分。

  定义条款即对合同中涉及的术语及名词作出限定、解释的条款。它可以散见于合同各个部分,但对于一些大型的、重要的合同,通常将其置于第一章。

  I. 常见的定义语句常用mean, refer to, be construed as, include等来表达。如:

  1. "Territory" means the United States of America.“销售地区”是指美利坚合众国。

  2. “Commencement date” shall mean the date of signing this agreement by the last signing party hereto.

  “协议生效日”是指本“协议”最后签字的一方签署本“协议”的日期。

  3. The “agreement” herein referred to shall mean this agreement of agency by entrustment.

  “协议”在这里是指本委托代理协议。

  4. “Code” shall refer to the current and applicable Internal Revenue Code.

  “法”是指当前可用的国内税收法。

  5. Reference to any statutory provision shall be construed as a reference to the same as it may have been, or may from time be, amended, modified or re-enacted.

  引用法律规定理解为引用其本身外,还包括其修订、修正或重新实施案。

  6. "Expenses" include costs, charges and expenses of every description.

  “费用”包括各种形式的金钱支出。

  II. 还有一类特殊的定义语句,即对于「单、复数」及「阴、阳性」名词的范围定义。通常都是用include来表达:

  1. "Stock Certificate" includes "stock certificate" and "stock certificates".

  合同中的“股票”,包括单数与复数。

  2. "He" includes "he" and "she".

  合同中的“他”,包括“他”与“她”。

  3. Words using the singular or plural number also include the plural or singular number.

  采用单数或复数的单词也包括复数或单数。

  III. 定义语句中,有时需限定范围。而通常用得最多的是:“for the purpose of ”及“in relation to” 某概念的定义条款,如果适用范围仅限于合同的“特定部份”,可以用“for the purpose of ”来为定义条款起头。而如果定义条款是针对合同的“特定概念”,就用“in relation to”来界定。如下例:

  1. For the purpose of this Agreement, "Products" means all types of the machineries manufactured by Manufacturer as are specified in Attachment A hereto.

  本协议所称的“产品”,指制造人所制造如附件A表列之各式机器。

  2. "Address" means-

  (a) 就自然人而言in relation to an individual, his usual residential or business address; and

  (b) in relation to a corporation, its registered or principal office in the Republic of China.

  “地址”就自然人而言,指通常之居所或工作场所;就公司而言,指位于中华人民共和国之注册所在地或主营业所。

  IV. 在定义条款中,在定义语句前有时会加上一些陈述语句来引导,如:

  1. For the purpose of this Agreement, each of the following terms shall have the following meaning respectively:

  就本合同的目的而言,下列各用语,分别具有下述意义:

  2. In this Agreement, the following words or expressions shall have the meanings given to them respectively below:

  本协议内所用词句的意义,明确阐述如下:

  3. In this agreement unless the context otherwise requires, the following words and expressions shall have the meanings assigned to them hereunder:

  除非本“协议”有明确规定,下列词语应当具有如下规定之意义:

  4. The following are the definitions of various terms used in this Agreement:

  本“协议”使用之术语定义如下:

  3. 有效期 Period of validity

  有效期(Term)条款通常规定合同的有效期限,何时生效及到何时结束,合同结束后必要时如何延展等等。

  I. 以下为“Term”的常用表达方式:

  The term of this contract is for a _____ year period.合同的有效期为_____年。

  如:The term of this contract is for a one (1) year period.

  2. The contract is for a _____ month period, commencing _____.

  合同的有效期为_____月,开始于______。(期限)

  a. The contract is for a 12 month period, commencing September 17, 20xx thru September 16, 20xx.

  b. The contract is for a 6 month period, commencing 4-1-03 and ending 9-30-20xx.

  3. This agreement remains valid for _____ year(s), i.e. commencing on ______, _____and terminating on ______, _____.

  本协议在_____年之内有效,即从_____年_____月_____日起生效,_____年_____月_____日起到期。

  4. The contract term is hereby extended for the period____.

  合同的有效期为_______。

  如:The contract term is hereby extended for the period____ in accordance with Section E, Paragraph 10, Term of Contract and Contract Extension.

  II. Term条款除了规定合同的期限外,通常另外合同期限的延展“Extension”。

  1. The contract period is for _____ year with option to re-new for _____ year.

  合同有效期为_____年,同时可以选择延长_____年。

  2. The contract is for a _____ month period, commencing _____. The contract may be renewed for up to _____ year option periods.

  合同的有效期为_____月,开始于_______,同时可以选择延长_____年。

  3. This agreement shall commence on the commencement date and shall endure for a continuous period of _____ years. Thereafter it will be automatically renewed for successive periods of _____ years on the same terms and conditions unless one of the parties had given _____days notice of termination.

  本协议应自生效日生效并在_____年内有效。此后,除非一方当事人提前_____天书面通知对方当事人终止本协议,本协议有效期自动延长_____年,协议条款不变。

  III. Term条款并没有十分固定的表达方式,以下即是一些合同中Term的实例:

  1. This Agreement shall be valid and remain in force for a period of three (3) years commencing from the date appearing first above written upon the signing of both Party A and Party B and shall be extended for another period of three (3) years on the same terms and conditions unless either of the parties hereto gives the other party at least thirty (30) days prior written notice to terminate this Agreement prior to the expiration of the original term.

  本合约须从上面首次写明的甲方和乙方签订本约的日期起生效并保持效力三年,并将按同样条件延长三年,否则与约任何一方至少须在原定时间期满前三十天给予另一方提前终止本合约的书面通知。

  2. At any time and from time to time during the period commencing on the date hereof and terminating on ______, 20___, party A may in writing advise party B.

  自本协议签订之日起到______年______月协议终止这段期间内,甲方可随时以书面形式通知乙方。

  3. The term of this Agreement shall be three years from the effective date, unless terminated in accordance with Article VI- (3) and Article IX.

  本合同的期限除非根据第8条第3款及第9条的规定终止外,有效期为3年。

  4. The contract is valid from _______ until _______.

  The contract period is automatically extended for any leave of absence allowed for in law.

  合同的有效期为从______到_____。

  5. The term of this Agreement shall commence on the _____ day of _____ and end on the _____ day of _____ Upon expiration of the above initial term, this Agreement shall automatically be renew and extended for a like period of time unless terminated in writing by either party _____ days prior to the date for such renewal.

  本协议期限为__年____月____日至__年___月___日。除非续订日前_____天一方以书面方式提出终止,否则上述首期届满后,协议应自动续订,延长时间与前期相同。

  4. 不可抗力 Force Majeure

  Force Majeure条款是一种免责条款,即免除由于不可抗力事件而违约的一方的违约责任。一般应规定的内容包括:不可抗力事件的定义(Definition of Force Majeure)以及不可抗力事件的后果(Consequences of Force Majeure) 。在Force Majeure条款中,两者属于因果关系,难以截然分开。

  I. 对于Force Majeure的定义,《合同法》定义如下:

  本法所称不可抗力,是指不能预见、不能避免并不能克服的客观情况。

  For purposes of this Law, force majeure means any objective circumstance, which is unforeseeable, unavoidable and insurmountable.

  II. 以下是Force Majeure条款的举例:

  1. Neither party shall be responsible for delays or failures in performance resulting from acts or facts reasonably beyond the control of that party.

  任何一方不应对因其无法控制之行为或事实造成协议延迟履行或不履行承担任何责任。

  2. Either Party shall not be liable for any delay caused by any unpredictable factor or any factor which is unavoidable or insurmountable by reasonable means at the time of conclusion of this Agreement, or any loss caused by failure in fulfillment of obligations as stipulated herein.

  协议任一方无须对因任何在本协议签订时无法预见或以合理手段也无法避免或克服之原因造成的迟延或不履行本协议之义务所造成的损失承担责任。

  注:以上采用的是类似《合同法》概括的定义方法。而合同为不可抗力定义时更多地采用列举的方法。

  3. Neither party of this Agreement, directly or indirectly owing to any causes or circumstances beyond its control, including Acts of God, Governmental orders or restriction, war, warlike conditions, revolutions, strike, lockout, fire and flood.

  本合同任何一方当事人对直接或间接地由于其无法控制的原因或情况包括自然灾害、政府命令或限制、战争、战争状态、革命、罢工、工厂被关闭、火灾、水灾等而未能履行或延迟履行合同或合同一部分的行为,不负任何责任。

  注: Acts of God通常也译为“不可抗力”,但主要是指自然灾害;而Force Majeure则包括自然及人为两方面。

  4. Neither party will be liable for nondelivery, misdelivery or late delivery (other than the payment of money due hereunder) caused by circumstances beyond its reasonable control, including, among others, war, civil strife or commotion, riots, strikes, fires, floods, acts of God, inability to obtain materials, failure of carriers or compliance with any law, regulation or governmental order.

  任何当事人将不会为任何因为不可控制的情况产生的未交付货物、交付错误或延迟交货(除了支付应付款)。不可控制的情况包括战争、国内斗争或*乱、骚乱、罢工、火灾、洪灾、自然灾害、无力获得材料、承运人的失误、遵守法律、法规或政府令。

  5. Should either of the parties to the contract by prevented from executing the contract by force majeure, such as earthquake, typhoon, flood, fire and war and other unforeseen events, and their happening and consequences are unpreventable and unavoidable, the prevented party shall notify the other party by cable without any delay, and within 15 days thereafter provide the detailed information of the events and a valid document for evidence issued by the relevant public notary organization

  for explaining the reason of its inability to execute or delay the execution of all or part of the contract. Both parties shall, through consolations, decide whether to terminate the contract or to exempt the part of obligations for implementation of the contract or whether to delay the execution of the contract according to the effects of the events on the performance of the contract.

  由 于地震、台风、水灾、火灾、战争以及其它不能预见并且对其发生和后果不能防止或避免的不可抗力事件出现,致使直接影响合同的履行或者不能按约定的'条件履行 时,遇有上述不可抗力的一方,应立即电报通知对方,并应在十五天内,提供不可抗力详情及合同不能履行、或者部分不履行、或者需要延期履行的理由的有效证明 文件。此项证明文件应由事故发生地有权证明的机构出具。按其对履行合同影响的程度,由双方协商决定是否解除合同,或者部分履行合同,或者延期履行合同。

  6. Force majeure shall hereof consist of the following events:

  下述事件构成不可抗力:

  Where such cases as war, earthquake, serious windstorms, snow, or fire or other events which no party can foresee and prevent from happening occur;

  发生战争、地震、严重的风灾、雪灾、火灾或其他各方无法预见、无法抗拒的事故。

  The related laws and regulations in collection with the execution of duties by any party to this Agreement undergo changes, under which this Agreement will be illegal or the transfer cannot be fulfilled.

  自本协议签订之日起与本协议任何一方履行本协议相关的法律、法规发生变更致使本协议非法或转让行为无法完成。

  In event of the occurrence of the above-mentioned events, if any party (hereinafter referred to as the “Effected Party ”) has been delayed or deterred from performing the duties of this Agreement in the course of its execution, the Affected Party shall be free from any liabilities for breach of the agreement and for compensation.

  在发生本协议不可抗力事件之后,任何一方(以下简称受影响方)在履行本协议义务时受到拖延或不能履行时,受影响方不承担任何违约责任及赔偿责任。

  In event of the force majeure, the affected party shall, within _____days from the date of the occurrence, notify the other party of the impact of such events on the execution of the duties in this Agreement, by telex, telegraph or in any other lawful written form, and simultaneously submit the relevant official credentials concerning the force majeure herein.

  在发生不可抗力事件时,受影响方应自不可抗力事件发生之日起_____天内以电传或电报或其他任何合理书面方式,通知另一方有关不可抗力的发生和不可抗力对其履行本协议的义务的影响,同时应呈交不可抗力的有关官方证明。

  Should the effect of the force majeure cases last more than _____ days, both parties shall consult each other about the alterations of this Agreement; in case they fail to reach an agreement, Chapter 8 shall thereupon apply.

  在不可抗力事件延续_____天后,双方必须磋商本协议的变更,双方未能协商一致的,适用本协议第八章的规定。

  7. Force Majeure不可抗力

  (1) No party to this Contract shall be liable to the other party for any failure of or delay in performance of its obligations hereof nor be deemed to be in breach of this Contract, if such failure or delay has arisen from "force majeure."

  如果任何一方因不可抗力而款能履行或推迟履行其义务,则不对另一方负责,也不应视作违反合同。

  "Force Majeure" means circumstances and conditions beyond the control of either parties, that would render it impossible for either the Owner or the Contractor to fulfill their obligations under this Contract, or delay such fulfillment. Any of the following matters are considered "force majeure."

  “不可抗力”指业主或承包商无法控制的情况,使当事人未能按本合同履行其义务,或者不得不延迟履行其义务。下列情况均被视作“不可抗力”:

  a. war, hostilities, act of foreign enemy, invasion, warlike opera-tions (whether war to be declared or not) or civil war;

  b. mutiny, civil commotion assuming the proportions of or amounting to a popular rising, military rising, insurrection, rebellion, revolution, military or usurped power, or any act of any person acting on behalf of or in connection with any organization with activities directed towards the overthrow by force of the Government de jure or de facto, or to the influencing of it by terrorism or violence;

  c. earthquake, flood, fire or other natural physical disaster;

  d. denial of the use of all ports, airports, shipping services or other means of public transport;

  e. strike or lock out or other industrial concerted action by workers, affecting the fulfillment of Contractors and subcontractors obligations;

  f. and other unforeseen circumstances beyond the control of the parties so affected rendering the fulfillment of their obligations impossible.

  a. 战争、敌对事件、外敌行动、入侵、类似战争的军事行动(不管是事宣战)、内战;

  b. 士兵哗变、民众*乱、军事叛乱、起义、造反、革命、篡权、或者任何个人代表某个组织或与某个组织有联系、旨在以暴力推翻合法或现存政府、或以恐怖主义或暴力对政府施加影响的行为;

  c. 地震、洪水、火灾或其他自然灾害;

  d. 所有港口、机场、船运或其他公共交通工具的使用均遭拒绝;

  e. 工人罢工、工厂停工、或其他的劳工联合行动,影响了承包商和分包商履行其义务;

  f. 当事人无法控制、从而使其不能履行义务的其他任何意外情况。

  (3) If either party to this Contract is prevented or delayed from or in performing any of his obligations under this Contract by force majeure, then he may notify the other party of the circumstances constituting the force majeure and of the obligation performance of which is thereby delayed or prevented and the party giving the notice shall thereupon be excused from the performance or punctual performance, as the case may be, of such obligation for so long as the circumstances of prevention or delay may continue.

  如果本合同任何一方因不可抗力不能或延迟履行本合同规定的任何义务,他可将不可抗力和由此造成的延迟或妨碍情况通知另一方。发出通知的一方允许根据具体情况及妨碍或延迟持续的时间免于履行或推迟履行合同。

  (4) If by virtue of the preceding sub-clause dither party shall be excused from the performance or punctual performance of any obligation for a continuous period of ________ months, then either party may at any time thereafter terminate this Contract by giving a written notice to the other party.

  根据本第款第3分条规定,如果任何一方免于履行或推迟履行其义务的时间持续了____个月,那么任何一方都可随时向另一方发出书面通知,终止本合同。

  5. 修改 Modification

  合同修订 (Modification)条款为合同常用条款.主要规定了合同修订的方式与途径。例如:书面合同,只能以书面方式进行修订,口头修订内容无效。

  I. Modification条款通常较为简单,以下为一些常用比较简约的表达方式:

  1. The contract can be amended only after the amendment is agreed upon by both parties.

  只有经双方一致同意,合同方可变更。

  2. This Agreement may be amended only by a written instrument signed by duly authorized representatives of both parties.

  本合同只有经双方当事人授权的代表正式签署的书面文件,方可修改。

  3. This Agreement may not be amended or modified except by written instrument signed

  by each of the Parties hereto.

  除非经本协议当事人签署的书面通知,否则本协议书不得作出任何修改和变更。

  4. Any alterations or amendments of this Agreement shall be subject to agreement through consultation between both parties in writing.

  本协议的任何变更或修改,应由本协议双方协商一致,并以书面方式进行。

  5. This Agreement shall not be modified or amended except by a written instrument, signed by the parties hereto.

  除非双方当事人共同签署书面文件,否则本“协议”不得修改或修订。

  6. Any modification, amendment or waiver of any of the provisions of this Agreement must otherwise be made in writing and duly signed by the parties hereto.

  对本“协议”任何规定的任何变更、修改或免责必须另以书面形式作出,并经各方正式签字。

  7. During the period of validity of the agreement, either party shall be entitled to make proposal of amendment to the agreement and the agreement amended shall go into effect with the signature of the two parties.

  在协议的有效期内,任何一方都有权提出对协议进行修改,修改后的协议经过双方签署后才能够生效。

  II. 在实际运用中,由于内容环境不同,表达可能有所不同,以下为一些实例:

  1. If the loan contract affiliated to this Contract has to be abridged, amended, or revised, both parties shall negotiate to amend and revise this Contract in line with the provisions of the loan contract.

  本股权质押项下的贷款合同如有修改、补充而影响本质押合同时,双方应协商修改、补充本质押合同,使其与股权质押项下贷款合同规定相一致。

  2. If this Contract shall be abridged, revised, or amended on account of force majeure, the responsibilities assumed by the Party A under this Contract shall not be exempted or reduced, and the rights and interests of the Party B under this Contract shall not been affected or infringed.

  如因不可抗力原因致本合同须作一定删节、修改、补充时,应不免除或减少甲方在本合同中所承担的责任,不影响或侵犯乙方在本合同项下的权益。

  3. The amendment of the contract or other appendices shall come into force only after the written agreement signed by Party A and Party B and approved by the original examination and approval authority.

  对本合同及其附件的修改必须经甲、乙双方签署书面协议,并报原审批机构批准,方可生效。

  4. This Agreement may be amended in writing signed by both Parties. Unless otherwise expressly agreed to in such amendment, all terms and conditions of this Agreement shall apply to any such addition and all rights granted to Licensee under this Agreement shall terminate as to any such deletion.

  本协议可由「双方」书面签署予以修改。除在此种修改中另行明确同意外,本协议所有的条款和条件须适用于任何此类修改中所做的添加,而所有根据本协议而给予「被许可人」的权利对于任何此类修改中的删除事项而言将终止。

  6. 补偿 Indemnification

  损害赔偿(indemnification)条款,是减少合同风险的一个重要条款。该条款主要约定在第三者对合同提出权利主张时,另一缔约方应当对此承担责任。通常情况下,另一缔约方必须支付全部的防御性诉讼费用,以及全部的支付给第三者的和解费用或者第三者胜诉后造成的所有损失。

  实际上,本条款是将第三人造成的风险从合同的一方当事人转移给另一方当事人。

  其次,本条款也可以约定合同的另一缔约方有其他不当的作为时,应当进行损害赔偿。

  I. Indemnification 条款常用“indemnify and hold harmless from……”来表达:

  1. Party A agrees to indemnify and hold Party B harmless from any claim or demand, including reasonable attorneys fees, made by any third party due to or arising out of

  甲方同意对乙方因_____造成的损失作出赔偿及保证乙方不招致任何第三方索偿或索求,包括合理的律师费用。

  应用实例:

  Party A agrees to indemnify and hold Party B harmless from any claim or demand, including reasonable attorneys fees, made by any third party due to or arising out of Party As use of the Site, the violation of this Agreement by Party A, or the infringement by Party A, or other user of the Site using Party As login name and password, of any intellectual property or other right of any person or entity.

  甲方同意对乙方因甲方使用网站、或甲方违反本协议、或因甲方或其它使用甲方之登记名称及密码而使用网站的使用者,侵犯任何知识产权或任何其它人士或单位的其它权利所造成的损失作出赔偿及保证乙方不招致任何索偿或索求,包括合理的律师费用。

  2. Party A shall indemnify and hold party B and each of party B officers, directors, stockholders, employees and agents harmless against, and in respect of, any damage, loss, liability, cost or expense, including attorneys, fees, resulting or arising from or incurred in connection with this Agreement and the transactions contemplated hereby, except such as may result from willful malfeasance if party B or such officer, director, stockholder, employee of agent, as the case may be.

  甲方应当赔偿乙方及其每个职员、董事、股东、雇员及其代理人因此协议引起或与此协议以后的交易相关事项而产生的损害、损失、责任、开支或费用,包括律师费用,但因乙方或其职员、董事、股东、雇员或代理人有意的过失而引起的损失除外。

  3. Each party will defend, indemnify and hold the other harmless from and against all actions, proceedings, claims, demands, suits, losses, damages and expenses, including reasonable attorneys fees and costs reasonably incurred in defending any proceedings in which the damages sustained arose from a failure of the other party to meet its obligations under this agreement. In no event will either party be liable to the other in connection with this agreement for special, incidental, indirect or consequential or punitive damages regardless of whether either or both parties knew of the possibility of such damages.

  一方当事人将使另一方当事人免于承担诉讼、索赔、请求、损害赔偿金及费用,包括为以下诉讼辩护而发生的合理的律师费:因另一方当事人未根据本协议履行其义务而导致损害赔偿的诉讼。

  不管一方当事人或双方当事人是否知道特殊损害赔偿、附带损害赔偿、间接损害赔偿、后果性损害赔偿、惩罚性损害赔偿发生的可能性,一方当事人均不会为另一方当事人承担上述损害赔偿。

  4. Contractor agrees to protect, defend, indemnify and hold harmless company, its parent, subsidiaries and affiliated companies, and its and their employees, subcontractors and its and their insurers from and against any claim, demand, cause of action, loss, expense award, obligation to indemnify another, judgment or liability on account of illness, injury or death to the employees of contractor and contractor’s subcontractors and/or damage to or loss or destruction of the property of contractor arising directly or indirectly out of the performance of this contract regardless of omissions or negligence, in whole or in any part, of company.

  承包商同意保护、辩护、赔偿和保证公司、其上级公司、下属公司和关联公司、及其雇员、次承包商和其保险公司不承担在履行本合同过程中,不论公司是否存在部分 或全部的不作为或疏忽的责任,直接或间接所导致的承包商和次承包商的雇员生病、受伤或死亡以及承包商的财产所遭受的毁损灭失相关的任何诉求、要求、诉因、 损失、费用、对他方的赔偿义务、判决或赔偿责任。

  II. Indemnification 条款还有多种表达方式,但并不固定。

  1. Notwithstanding any of indemnities and liabilities specifically referred to above, neither company or contractor shall be liable to the other with respect to any consequential loss including, but not limited to, loss of anticipated profit, loss of anticipated revenue, loss of anticipated production, loss of product, or loss of use of money, arising or alleged to arise out of either company’s or contractor’s failure to property carry out its obligations hereunder or due to omissions or negligence, in whole or any part, of the part at fault, its subcontractors or vendors or the un-seaworthiness of vessel, or strict liability, and regardless of whether pre-existing the execution of the agreement.

  除上列特别述及的赔偿和责任外,公司或承包商相互间不承担任何间接损失,包括但不限于预计的利润损失、预计的收益损失、预计的生产损失、产品损失、无法使用金钱的损失,由于或认为系因公司或承包商未能正确地履行本合同的义务或由于该违约系由于其次承包商或供应商(买方)或船舶不适航或严格责任和不论是否存在依以前协议履行原因,所导致的部分或全部的不作为或疏忽所造成的损失。

  2. All remedies specified herein or otherwise available shall be cumulative and in addition to any and every other remedy provided hereunder or now or hereafter available at law or in equity. No waiver or failure to act with respect to any breach or default hereunder, whether or not the other party has notice thereof, shall be deemed to be a waiver with respect to any subsequent breach or default, whether of similar or different nature.

  依据法律或衡平法,本“协议”所述的赔偿或其它可得的赔偿应当是累积的,并在本“协议”中规定的赔偿之外,或在现在或此后可得的赔偿之外。无论对方当事人通知与否,任何与违反协议或不履行协议有关的弃权不得视为与任何后来的违反协议或不履行协议有关的弃权,无论是否性质相同或不同。

  III.在大型合同中,Indemnification 条款往往非常复杂,以下即为。

  Indemnification 补偿

  (a) Each party shall indemnify and hold harmless the other party, its shareholders, directors, officers, employees, agents, designees and assignees, or any of them, from and against all losses, damages, liabilities, expenses, costs, claims, suits, demands, actions, causes of actions, proceedings, judgments, assessments, deficiencies and charges (collectively, "Damages") caused by, relating to or arising from the performance by such party in accordance with this Contract of its obligations hereunder, and Buyer shall also indemnify Seller, without limiting the foregoing, for any such item caused by, relating to or arising from (a) the programming services which are authorized for viewing sing the System, including any assertion that any such programming service involves copyright infringement, (b) any disputes between Buyer and any of its program distributors or other distributors or affiliates, (c) any disputes or claims involving the subscribers for Buyers programming services, or (d) any assertion that Buyer has been involved in, that Buyers conduct of subscription involves, or that Buyers use of the System involves, any unfair competition or violations of laws, rules or regulations.

  (a)每方应就其按本合同规定履行其本合同项下义务所导致的、与其有关的或由其引发的一切损失、损害、责任、支出、费用、索赔、诉讼、要求、诉讼行为、诉因、程序、判决、估定税额、欠额以及收费(合称“损害”)补偿另一方、另一方的股东、董事、管理人员、雇员、代理、被指定人、受让人或其中任何一人,使之不受损害,并且在不对上文所述予以限制的条件下,买方还应就下述各项所导致的、与其有关的或由其引发的上述任何事项补偿卖方:

  (a)授权对viewing sing系统提供的服务;(b)买方与项目分包商、分支机构之间的纠纷;(c) 任何用户针对买方的该项目服务的纠纷或索赔;(d) 针对买方所涉该系统的不正当竞争或违法指控。

  (b) In the event of a third-party claim, with respect to which a party’s entitled to indemnification hereunder, a party (the "Indemnified Party") shall notify the other party (the "Indemnifying Party") in writing s soon as practicable, but in no event later than ______ days after receipt of such claims. The Indemnified Partys failure to provide such noticed shall not preclude it from seeking indemnification hereunder unless such failure has materially prejudiced the Indemnifying Partys ability to defend such claim. The Indemnifying Party shall promptly defend such claim with counsel of its own choosing) and the Indemnified Party shall cooperate with the Indemnifying Party in the defense of such claim, including the settlement of the matter on the basis stipulated by the indemnifying Party (with the Indemnifying Party being responsible for all costs and expenses of such settlement).

  (b)如果第三方提出一方按本合同规定有权获得补偿的索赔请求,一方(“受补偿方”)应在实际可能的情况下尽早通知另一方(“补偿方”),但无论如何不得迟于在收到该等请求后的第_______日。受补偿方未给予该通知并不排除其按本合同规定寻求补偿,除非未给予该通知补偿方抗辩该索赔请求的能力受到实质影响。补偿方(与其自行选择的律师一起)应及时对该索赔请求进行抗辩,而受补偿方应在对该索赔请求进行抗辩时与补偿方合作,包括按照补偿方规定的原则就该事项达成和解(补偿方承担该和解的一切费用与支出)。

  If the Indemnifying Party within a reasonable time after notice of a claim fails to defend the Indemnified party, the Indemnified Party shall be entitled to undertake the defense, compromise or settlement of such claim at the expense of the Indemnifying arty. Upon the assumption of the defense of such claim, the Indemnifying arty may settle, compromise or defend as it sees fit. Notwithstanding anything to the contrary set forth in this Section, seller will defend any suit, claim, action or proceeding brought against buyers to the extent that such suit, claim, action or proceeding is based on a claim that goods manufactured and sold by Seller to Buyer infringe patent, copyright, mask work, trademark, trade secret or any other intellectual property rights of any third party and Seller shall pay all damages and costs awarded by final judgment (from which no appeal may be taken) against Buyer, as well as its actual expenses and costs, on condition that Seller

  如果补偿方收到索赔通知后为受补偿方辩护,则受补偿方应有权对该索赔进行抗辩、妥协或和解,费用由补偿方承担。在承担对该等索赔请求的辩护后,补偿方可进行和解、妥协或抗辩,由其酌处。无论本条有何相反的规定,如果发生对买方的诉讼、索赔、诉讼行为或程序是基于以下主张,即卖方制造并销售给买方的物品侵犯了任何第三方的_______国专利、版权、掩模、商标、商业秘密或其他任何知识产权,则卖方将就该诉讼、索赔、诉讼行为或程序为买方辩护,并将支付局判决(不能再上诉的)判定由买方承担的损害赔偿与费用,以及买方实际的支出与费用,上述规定的条件是:

  (i) is promptly informed and furnished a copy of ach communication, notice or other action relating to the alleged infringement, (ii) is given sole control of the defense (including the right to select counsel), and the sole right to compromise and settle such suit or proceeding; provided however, that Sellers liability hereunder, if any, shall be strictly and solely limited to the amount of royalties which would be payable in respect of revenues derived by Seller from Buyer from sales of the infringing goods. Seller shall not be obligated to defend or be liable for costs and damages if the infringement arises out if a combination with, an addition to, or modification of the goods after delivery by Seller, or from use of the goods, or any part thereof, in the practice of a process.

  (1)卖方被及时告知侵权指控的发生,并得到与该侵权指控有关的每一通讯、通知或其他诉讼文书的副本,(2)得到该辩护的独家控制权(包括选择律师的权利),以及就诉讼或程序进行妥协或者和解的独家权利;但是,卖方在本合同项下的责任(如果有的话),应严格地并且仅仅限于卖方因买方销售侵权物品而应从买方获得的特许权使用费收入金额。如果侵权是由卖方交货后有人将物品混合、添加或改造而引起,或者由实施某一方法时使用物品(或其何部分)而引起,则卖方无义务进行辩护,亦无承担费用或损害赔偿的责任。

  If any goods manufactured and supplied by Seller to Buyer are held to infringe any valid patent and Buyer is enjoined from using the same, or if seller believes such infringement is likely, Seller will exert all reasonable efforts at its option and expense (i) to procure for Buyer the right to use such goods free of any liability for such infringement, or (ii) replace or modify such goods with a noninfringing substitute otherwise complying substantially with all the requirements of this contract, or (iii) upon return of the goods, refund the purchase price and the transportation costs of such goods (less reasonable allowance for their use and benefit derived therefrom for the period of time from delivery to Buyer, such allowance being based on a straight-line depreciation period of _______ years from the date of shipment by Seller).

  如果卖方制造并向买方提供的任何物品被判定侵犯有效的_______国专利,且卖方被禁止使用该专利,或者如果卖方相信很可能发生侵权,卖方将尽一切合理的努力,自费从以下措施中作出选择:(1)为买方取得使用该等物品而不产生侵权责任的权利,或(2)以在其他方面实质符合本合同所有规定的非侵权替代品来代替或改造该等物品,或(3)在该等物品被返还后,退还该等物品的购买价以及运费(扣除向买方交货至退还期间使用该等物品并从中获得利益的折扣金额,该折扣金额按从卖方装运之日起_______年直线式折旧来计算)。

  If the infringement is alleged prior to completion of delivery of the goods, Seller has the right to decline to make further shipments without being in breach of contract. If Seller has not been enjoined from selling such goods to Buyer, Seller may (at Sellers sole election), at Buyers request, supply such goods to Buyer, in which event Buyer shall be deemed to extend to Seller the same patent indemnity hereinabove stated. The same patent indemnity shall be deemed to be extended to Seller by buyer if any suit or proceeding is brought against Seller based on a claim that the goods manufactured by Seller in compliance with Buyers specifications infringe any valid patent. Buyer shall promptly notify Seller of any infringement by a third party of intellectual property rights licensed to Buyer under this contract. In the event that a third party infringes such intellectual property rights, the Parties shall cooperate with one another to take appropriate action to cause such infringement to cease. The foregoing states the sole and exclusive liability of the parties hereto for infringement of patents, copyrights, mask works, trade secrets trademarks, and other proprietary rights, whether direct or contributory, and is in lieu of all warranties, express, implied or statutory, in regard hereto, including, without limitation, the warranty against infringement specified in the uniform commercial code.

  如果交货完成前发生权指控,卖方有权拒绝进一步装运,而不构成违约。如果卖方还没有被禁止向买方销售该等物品,应买方请求,卖方可以(仅由卖方酌定)向买方供应该等物品,在此情况下,买方应被视为向卖方做出与本合同上文所述相同的专利补偿保证。如果有人指称卖方按照买方规格制造的物品侵犯了有效的_______国专利,并以此为根据向卖方提起诉讼或程序,则买方应被视为已向卖方做出同样的专利补偿保证。

  买方应将第三方侵犯本合同项下许可给买方的知识产权及时通知卖方。如果第三方侵犯该等知识产权,双方应互相合作,采取适当的行动制止该侵权行为。

  上文规定了本合同双方就专利、版权、掩模、商业秘密、商标以及其他专有权利的侵权(无论是直接的还是协从的)所承担的唯一责任,并且取代就其所做出的所有保证(明示的、暗示的或法定的),包括(但不限于)_____中规定的不侵权保证。

  英文合同7

  SALES CONTRACT

  NO.:BS08125 DATE: NOV.6,20xx

  THE SELLER: BLUE SKY INTERNATIONAL TRADING CO.,LTD.

  118# 5TH NORTH RING ROAD, BEIGING, P.R.CHINA

  THE BUYER:STAR CORPORATION

  5 KINGROAD DUBAI, UAE

  This Contract is made by and between the Buyer and Seller, whereby the Buyer agree to buy and the Seller agree to sell the under-mentioned commodity according to the terms and conditions stipulated below:

  数量和金额可以上下浮动5%

  PACKING:20 pieces of Baby Blankets are packed in one export standard carton, solid color and size in the same carton. 包装:20条童毯被装进一项输出品标准硬纸盒、一样颜色和尺寸的装在相同的硬纸盒。

  MARKS: Shipping mark includes STAR ,S/C No. ,style No. , port of destination and carton No. 唛头:运输唛头包括STAR(公司名)、合同(sales contract)号码,款式号码,目的港和纸箱号码

  Side mark must show the color, the size of carton and pieces per carton.

  侧唛头必须显示纸箱颜色,规格和每箱(童毯)条数

  TIME OF SHIPMENT:装运期

  Within 60 days upon receipt of the L/C which accord with relevant clauses of this Contract.收到符合合同的信用证,六十天内

  PORT OF LOADING AND DESTINATION: From Tianjin, China to Dubai, UAE

  装运港 目的港

  Transshipment is allowed and partial shipment is prohibited.

  转运被允许,而且分批装运被禁止。

  INSURANCE: To be effected by the Seller for 110% of invoice value covering All Risks and War Risks as per CIC of PICC dated 01/01/1981.保险:卖方按合同金额的110% 投保 包含的一切险和战争险依照1981年的 PICC 规则的 CIC 条约。

  TERMS OF PAYMENT: By irrevocable Letter of Credit at 60 days after sight, reaching the Seller not later than Nov.30, 20xx and remaining valid for negotiation in China for further 15 days after the affected shipment. In case of late arrival of the L/C, the Seller shall not be liable for any delay in shipment and shall have the right to rescind the contract and /or claim for damages.付款期限:不可撤销信用证,见票后60天付款.卖方收到信用证不得晚于08年11月30号。偿付通知议付在中国 装船后15天内提交单据,如果信用证迟到,卖方将不负责装船中的`任何延迟而且将有权利废止合同和│或损害要求(赔偿)。

  DOCUMENTS:文件

  +Signed invoice in triplicate, one original of which should be certified by Chamber of Commerce or CCPIT and legalized by UAE embassy/consulate in seller’s country.

  +签署的单据一式三份,一份正本应该被商会或 CCPIT (贸促会)检定而且在卖方的国家被阿拉伯联合大公国大使馆│领事法律上认为正当。

  +Full set (3/3) of clean on board ocean bill of lading marked “freight prepaid” made out to order blank endorsed notifying the applicant.

  +全套 (3|3) 清洁海运提单 标记" 船货预付 " 空白抬头提单通知申请人。 +Insurance policy in duplicate endorsed in blank.

  +保险单一式两份空白背书。

  +Packing list in triplicate.

  +包装目录一式三份

  +Certificate of origin certified by Chamber of Commerce or CCPIT and legal

  ized by UAE embassy/consulate in seller’s country.

  +被商会或 CCPIT(贸促会) 检定的原产地证明书而且在卖方的国家根据阿拉伯联合大公国大使馆│领事法律上认为正当。

  INSPECTION: The certificate of quality issued by the China Entry-Exit Inspection and Quarantine Bureau shall be taken as the basis of delivery.

  检验:质量证书根据中国进出口检验检疫局发行,将当做交付的基础。

  CLAIMS: In case discrepancy on the quality or quantity of the goods is found by the Buyer, after arrival of the goods at the port of destination, the Buyer may, within 30 days and 15 days respectively after arrival of the goods at the port of destination, lodge with the Seller a claim which should be supported by an Inspection Certificate issued by a public surveyor approved by the Seller. The Seller shall, on the merits of the claim, either make good the loss sustained by the Buyer or reject their claim, it being agreed that the seller shall not be held responsible for any loss or losses due to natural cause failing within the responsibility of Ship owners of the Underwriters. The Seller shall reply to the Buyer within 30 days after receipt of the claim.

  索赔:买方发现货物在质量和数量上有差异,货物到达目的港后,买主可以,在30 天到15 天之内,在货物抵达后在目地港,向卖方提出要求,要求应该被一份被卖方核准的公众的检查官发行的检验证书支援。卖方,在在赔偿要求中,要么承受买方损失 要么拒绝索赔,经双方同意,卖方将不承担任何损失 或者 损失是由自然原因将或由船方造成的损失 卖方应在30天内答复买方。

  LATE DELIVERY AND PENALTY: In case of late deliver, the Buyer shall have the right to cancel this contact, reject the goods and lodge a claim against the Seller. Except for Force Majeure, if late delivery occurs, the Seller must pay a penalty, and the Buyer shall have the right to lodge a claim against the Seller. The rate of penalty is charged at 0.5% for every 7 days, odd days less than 7 days should be counted by the paying bank or the Buyer from the payment.

  迟期交货及刑罚:以防迟到的传递,需方有权取消这个合同,拒绝接受货物和向卖方提出索赔。除不可抗力,如果迟期交货时,卖方必须支付违约金,买方有权向卖方提出索赔。罚金是0.5%,每7天,天数不到7天应安7天算 由银行付款银行或由买方的货款中扣除。

  FORCE MAJEURE: The Seller shall not held responsible if they, owing to Force Majeure cause or causes, fail to make delivery within the time stipulated in the Contract or cannot deliver he goods. However, in such a case, the Seller shall inform the Buyer immediately by cable and if it is requested by the Buyer, the Seller shall also deliver to the Buyer by registered letter, a certificate attesting the existence of such a cause or causes.

  不可抗力:卖方不负责,但卖方必须立即以传真或原因,不可抗力原因,未能交货时间内应收的合同或不能救他的货物。然而,在这种情况下,卖方应立即以电报通知买方。如果是按照买主的要求,卖方应负责向买方把挂号信,证书,证明这样的原因还是存在的原因。

  ARBITRATION: All disputes in connection with this contract or the execution thereof shall be settled amicably by negotiation. In case no settlement can be reached, the case shall then be submitted to the China International Economic Trade Arbitration Commission for settlement by arbitration in arbitration in accordance with the Commission’s arbitration rules. The award rendered by me commission shall be final and binding on both parties. The fees for arbitration shall be borne by the losing

  party unless otherwise awarded.

  仲裁:凡有关本合同或实施应通过友好协商予以解决。若通过友好协商未能达成协议,则应提交中国国际经济贸易仲裁委员会仲裁在解决根据该会的仲裁规则进行仲裁。我的裁决是中局的,对双方都有约束力。仲裁费用应由败诉方承担除非另有判决。

  This contract is made in four original copies and becomes valid after signature, two copies to be held by each party.

  本合同正本及成为四个有效签名后,双方各两份。

  Signed by:

  THE SELLER:

  BLUE SKY INTERNATIONAL TRADING CO, .LTD.

  Tian Fang THE BUYER: STAR CORPORATOON Lamia Khashoggi

  英文合同8

  合同编号:_________________

  Contract No:_______________

  签订日期:_________________

  Date:______________________

  签订地点:_________________

  Signed at : _______________

  电 话:____________________

  Tel: ______________________

  传 真:____________________

  Fax:_______________________

  电 报:____________________

  Cable: ____________________

  电 传:____________________

  Telex: ____________________

  电 话:____________________

  Tel: ______________________

  传 真:____________________

  Fax:_______________________

  电报:_____________________

  Cable: ____________________

  电传:_____________________

  Telex: ____________________

  经买双方确认根据下列条款订立本合同:

  The undersigned Sellers and Buyers have confirmed this contract in accordance with the terms and conditions stipulated below :

  1. 货号

  Art No. 名称及规格

  Descriptions 单位

  Unit 数量

  Quantity 单价

  Unit Price 金额

  Amount

  合计:_________________

  Totally:______________

  总值(大写):_____________________

  Total value:(in words)_____________

  允许溢短____%。________% more or less in quantity and value allowed.

  2.成交价格术语:

  Terms: □ FOB □ CFR □ CIF □ DDU □

  3.出产国与制造商:___________________________

  Country of origin and manufacturers : ________

  4.包装:__________________

  Packing: __________________

  5.装运唛头:______________

  Shipping Marks: ___________

  6.装运港:________________

  Delivery port : ___________

  7.目地港:________________

  Destination: ______________

  8.转运:□ 允许 □ 不允许; 分批装运:□ 允许 □ 不允许

  Transhipments: □ allowed □ not allowed

  Partial shipments:□allowed □ not allowed

  9.装运期:________________

  Shipment date: ____________

  10.保险:由____按发票金额110%,投保_____险,另加保_____险。

  Insurance : to be covered by the FOR 110% of the invoice value covering additional

  11.付款条件:

  Terms of payment:

  □买方通过_____银行在____年____月____日前开出以卖方为受益人的_______期信用证。

  The buyers shall open a Letter of Credit at sight through bank in favour of the sellers prior to .

  □付款交单:买方应对卖方开具的以买方为付款人的见票后_____天付款跟单汇票,付款时交单。

  Documents against payment (D/P)

  The buyers shall duly make the payment against documentary draft made out to the buyers at sight by the sellers.

  □承兑交单:买方应对卖方开具的以买方为付款人的见票后_____天承兑跟单汇票,承兑时交单。

  Documents against acceptance: (D/P)

  The buyers shall duly make the payment against documentary draft made out to the buyers at sight by the sellers.

  □货到付款:买方在收到货物后____天内将全部货款支付卖方(不适用于FOB、CFR、CIF术语)。

  Cash on delivery (COD)

  The buyers shall pay to the sellers total amount within days after the receipt of the goods .(This clause is not applied to the terms of FOB,CFR,CIF).

  □

  12.单据:卖给方应将下列单据提交银行议付/托收。

  Documents :The sellers shall present the following documents required to the banks for negotiation/collection.

  ① 运单

  Shipping Bills :

  □ 海运:全套空白抬头/指示抬头、空白背书/指示背书注明运费已付/到付的已装船清洁海运/联运正本提单,通知在目的港 公司

  In case by sea : Full set of clean on board ocean Bills of Lading / combined transportation Bills of Lading made out to order blank endorsed / endorsed in favour of or made out to order of ,marked “freight prepaid / collected ” notifying at the port of destination .

  □ 陆运:全套注明运费已付/到付的装车的记名清洁运单,通知在目的地 公司。

  In case by land transportation: full set of clean on board land transportation Bills made out to marked “freight prepaid / collected ” notifying at the destination.

  □空运:全套注明运费已付/到付的记名空运单,通知在目的地 公司。

  In case by Air : Full set of clean on board AWB made out to marked “freight prepaid/collected”notifying at

  the destination .

  □ :

  ②标有合同编号信用证号及装运唛头的商业发票一式____份。

  Singed commercial invoice in copied indicating contract No, L/C No. And shipping marks.

  ③由_____出具的装箱单或重量单一式______份。

  Packing list / weight memo in copies issued by .

  ④由_______出具的质量证明书一式________份

  Certificate of Quality in copies issued by .

  ⑤由________出具的数量证明书一式________份

  Certificate of Quantity in copies issued by .

  ⑥保险单正本一式_______份。

  Insurance policy / certificate in copies .

  ⑦ 签发的`产地证一式_______份

  Certificate of Origin in copies issued by .

  ⑧装运通知:

  shipping advice:

  另外,卖方应在交运后____小时内以特快专递方式邮寄给买方第____项单据副本一套。

  In addition , the sellers shall, within hours after shipment effected , send each copy of the above—mentioned documents No.____, directly to the buyers by courier service.

  13.装运条款:

  □ FOB

  卖方应在合同规定的装运日期前30天,以电报/电传/传真通知买方合同号、品名、数量、金额、包装件、毛重、尺码及装运港可装日期,以便买方安排租船/订舱。装运船只按期到达装运港后,如卖方不能按时装船,发生的空船费或滞期费由卖方负担。在货物超过船舷并脱离吊钩以前一切费用和风险由卖方负担。

  The sellers shall , 30 days before the shipment date specified in the contract advise the buyers by CABLE / TELEX /FAX of the contract No. , commodity , quantity , amount , packages , gross weight , measurement , and the date of shipment in order that the buyers can charter a vessel / book shipping space . In the event of the sellers’ failure to effect loading when the vessel arrives duly at the loading port , all expenses including dead freight and / or demurrage charges thus incurred shall be for seller’s account.

  □ CIF或CFR

  CIF and CFR

  卖方须按时在装运期限内将货物由装运港装船到目的港。在CFR术语下,卖方应在装船前2天电传/传真/电报买方合同号、品名、发票价值及开船日期,以便买方安排保险。

  The sellers shall ship the goods duly within the shipping duration from the port of shipment to the port of destination . Under CFR terms , the sellers shall advise the buyers by CABLE/FAX/TELEX of the contract No. , commodity , invoice value and the date of despatch two days before the shipment for the buyers to arrange insurance in time.

  □ DDU

  卖方须按时在装运期限内将货物由装运港装运至目的港。

  The sellers shall ship the goods duly within the shipping duration from the port of the port of destination .

  □

  14.装运通知

  shipping advice :

  一件装载完毕,卖方应在____小时内电传/传真/电报买方合同编号、品名、已发运数量、发票总金额、毛重、船名/车/机号及启程日期等。

  The sellers shall immediately upon the completion of the loading of the goods , advise buyers of the contract No., names of commodity , loading quantity , invoice values , gross weight , name of vessel and shipment date by TLX/FAX/CABLE within _____hours .

  15.质量保证:

  Quality guarantee :

  货物品质规格必须符合本合同及质量保证书之规定,品质保证期为货到目的港_____个月内,在保证期限内,因制造厂商在设计制造过程中的缺陷造成的货物损害应由卖方负责赔偿。

  The sellers shall guarantee that the commodity must be in conformity with the quality and specifications specified in this contract and Letter of Quality Guarantee .The guarantee period shall be months after the arrival of the goods at the port of destination , and during the period the sellers shall be responsible for the damage due to the defects in designing and manufacturing of the manufacturer.

  16.商品检验:卖方须在装运前_____日委托 检验机构对合同之货物进行检验并出具检验证书,货到目的港后,由买方委托____检验机构进行复检。

  Goods inspection : The sellers shall have the goods inspected by Inspection Authority days before the shipment and issued the Inspection Certificate . The buyers shall have the goods reinspected by Inspection Authority after the goods arrival at the destination.

  17.索赔

  Claims:

  如经中国_____检验机构复检,发现货物有损坏、残缺或品名、规格、数量及质量与本合同及质量保证书之规定不符,买方可于货到目的港后 天内凭上述检验机构出具的证明书向卖方要求索赔。如上述规定之索赔期与质量保证期不一致,在质量保证期限内买方仍可向卖方就质量保证条款之内容向卖方提出索赔。

  The buyers shall lodge claims against the sellers based on the Inspection Certificate issued by China Inspection Authority Days after the arrival of the goods at the destination , if the goods are found to be damaged , missing or the specifications , quantity, and quality not in conformity with those specified in this contract and Letter of Quality Guarantee . In case the claim period above specified is not in conformity with the quality guarantee period, during the quality guarantee period, the buyers have rights to lodge claims against the sellers concerning the quality guarantee.

  18.延期交货违约金

  Late delivery and penalty

  除双方认可的不可抗力因素外,卖方迟于合同规定的期限交货,如买方同意迟延交货,卖方应同意对信用证有关条款进行个性和同意银行在议付货款时扣除本条规定的违约金。违约金总值不超过货物总价值的5%,差率按7天0.5%计算,不满7天仍按7天计算。在未采用信用证支付的情况下,卖方应将前述方法计算的违约金即付买方。

  If the sellers fail to make delivery on time as stipulated in the contract , with exception of Force Majeure, the buyers shall agree to postpone the delivery on conditions that the sellers agree to amend the clauses of the L/C and pay a penalty which shall be deducted by the paying bank from the payment under negotiation . The penalty , however , shall not exceed 5% of the total value of the goods . The rate of penalty is charged at 0.5%for every seven days , if less that seven days. In case , the payment is not made through L/C , the sellers shall pay the penalty counted as above to the buyers as soon as possible.

  19.人力不可抗拒:如因人力不可抗拒的原因造成本合同全部或部分不能履约,卖方概不负责,但卖方应将上述发生的情况及

  时通知买方。

  Force Majeure : The sellers shall not hold any responsibility for partial or total non-performance of this contract due to Force Majeure . But the sellers shall advise the buyers on times of such occurrence.

  20.争议之解决方式:

  Disputes settlement :

  □任何因本合同而发生或与本合同有关的争议,应提交中国国际经济贸易仲裁委员会,按该会的仲裁规则进行仲裁。仲裁地点在中国深圳。仲裁裁决是终局的,对双方均有约束力。

  All disputes arising out of the contract or in connection with the contract , shall be submitted to the China International Economic and Trade Arbitration Commission for arbitration in accordance with its Rules of Arbitration in ShenZhen China . The arbitral award is final and binding upon both parties.

  □

  21.法律适用

  Law application :

  本合同之签订地、或发生争议时货物所在地在中华人民共和国境内或被诉人为中国法人的,适用中华人民共和国法律,除此规定外,适用《联合国国际货物销售公约》。

  It will be governed by the law of the People’s Republic of China under the circumstances that the contract is singed or the goods while the disputes arising are in the People’s Republic of China or the deffendant is Chinese legal person , otherwise it is governed by United Nations Convention on Contract for the International Sale of Goods .

  22.本合同使用的FOB、CFR、CIF、DDU 术语系根据国际商会《Incoterms 1990》

  23.文字:本合同中、英两种文字具有同等法律效力,在文字解释上,若有异议,以中文解释为准。

  Versions : This contract is made out in both Chinese and English of which version is equally effective .Conflicts between these two language arising therefrom . if any , shall be subject to Chinese version .

  24.附加条款(本合同上述条款与本附加条款有抵触时,以本附加条款为准):

  Additional Clauses : (conflicts between contract clause here above and this additional clause , if any , it is subject to this additional clause)

  25.本合同共____份,自双方代表签字(盖章)之日起生效。

  This contract is in copies , effective since being signed / sealed by both parties:

  买方代表人:___________________________ 卖方代表人 :_________________________

  Representative of the buyers : _______ Representative of the sellers :______

  签字:_________________________________ 签字:________________________________

  Authorized signature :________________ Authorized signature : ______________

  英文合同9

  CONTRACT FOR IRANIAN OIL EXPLORATION SERVICE

  伊朗石油勘探开发服务合同

  EXPLORATION SERVICE CONTRACT FOR BLOCK between NATIONAL IRANIAN OIL COMPANY and CORPORATION

  伊朗国家石油公司 与石油公司 区块勘探服务合同

  Table of Contents目 录

  ARTICLE 1 DEFINITIONS第1条 定义

  ARTICLE 2 CONTRACTORs REPRESENTATIVE OFFICE第2条 承包商办事处

  ARTICLE 3 OBJECT OF THE CONTRACT第3条 合同宗旨

  ARTICLE 4 TERM OF THE CONTRACT第4条 合同期限

  ARTICLE 5 EXPLORATION OPERATIONS 第5条 勘探作业

  ARTICLE 6 FINANCING, EXPLORATION EXPENDITURES, REIMBURSEMENT AND PAYMENTS

  第6条 资金、勘探费用、回收和支付

  ARTICLE 7 CONDUCT OF OPERATIONS 第7条 作业实施

  ARTICLE 8 CONTRACTOR’S OBLIGATIONS 第8条 承包商的义务

  ARTICLE 9 SUB-CONTRACTORS 第9 条分包商

  ARTICLE 10 PROGRAMMING AND BUDGETING第10条 计划和预算

  ARTICLE 11 BOOKS, ACCOUNTS, VERIFICATION AND AUDITING

  第11条 账簿、账户、审核和审计

  ARTICLE 12 N.I.O.Cs TITLE TO LAND AND PROPERTY

  第12条 N.I.O.C.对土地和财产的所有权

  ARTICLE 13 COMMERCIAL FIELD第13条 有商业价值的油(气)田

  ARTICLE 14 LAND, WATER AND SERVITUDE 第14条 土地、水与地役权

  ARTICLE 15 UTILIZATION OF IRANIAN CONTENT第15条 伊朗资源的利用

  ARTICLE 16 IMPORTS AND EXPORTS 第16条 进口和出口

  ARTICLE 17 CURRENCY EXCHANGE RATES第17条 汇率

  ARTICLE 18 ASSIGNMENT 第18条 转让

  ARTICLE 19 LIABILITY AND INSURANCE第19条 责任和保险

  ARTICLE 20 FORCE MAJEURE第20条 不可抗力

  ARTICLE 21 WAIVERS 第21条 弃权

  ARTICLE 22 GOVERNING LAW 第22条 适用法律

  ARTICLE 23 ARBITRATION第23条 仲裁

  ARTICLE 24 CONTINUITY OF OPERATIONS第24条 作业的连续性

  ARTICLE 25 TERMINATION 第25条 合同终止

  ARTICLE 26 N.I.O.CS POWER OF CONTROL 第26条 N.I.O.C.的控制权

  ARTICLE 27 SAFETY, HEALTH AND ENVIRONMENT第27条 安全、健康和环境

  ARTICLE 28 CONFIDENTIALITY第28条 保密

  ARTICLE 29 HEADING AND AMENDMENTS第29条 标题与修订

  ARTICLE 30 NOTICE第30条 通知

  APPENDIX ACCOUNTING PROCEDURES附录 会计程序

  Service Contract服务合同

  This Service Contract entered into in Tehran on the day of.

  BETWEEN

  NATIONAL IRANIAN OIL COMPANY a company existing under the laws of IR of Iran (hereinafter referred to as "N.I.O.C") on the one hand and CORPORATION a company incorporated in (hereinafter referred to as "Contractor"), on the other hand,N.I.O.C and Contractor herein are referred to either individually as "Party" or collectively as "Parties".

  WHEREAS N.I.O.C desires to secure the cooperation and services of a qualified contractor to carry out, on its behalf and in its name, certain Exploration perations within the Contract Area specified in the Appendix A hereof.

  WHEREAS CONTRACTOR has expressed its willingness to perform such Exploration Operations in the manner specified in this Service Contract, and is prepared to provide the funding for and bear the sole risk of Exploration Operations on its own account.

  WHEREAS CONTRACTOR has the financial capability, and technical competence necessary for fulfilling the obligations set out hereinafter.

  NOW THEREFORE, it is hereby agreed between N.I.O.C and Contractor as follows:

  本服务合同由依照伊朗伊斯兰共和国法律成立的伊朗国家石油公司(以下简称N.I.O.C.)与公司(以下简称承包商)于在伊朗德黑兰订立。

  N.I.O.C.和承包商在下文中单独被称为“一方当事人”,合称为“双方当事人”。

  鉴于N.I.O.C.愿意寻找一合格的承包商代表其利益并以其名义在本合同附件A所指定的合同区域内实施一定的勘探作业。

  鉴于承包商愿意按本合同所规定的形式实施勘探作业,并准备提供资金和独立承担勘探作业的风险。

  鉴于承包商具备履行以下所述义务所必需的资金能力和技术能力。

  基于此,N.I.O.C.与承包商同意以下条款:

  ARTICLE 1 DEFINITIONS第1条 定义

  Unless the context otherwise requires the following definitions of certain terms hereinafter used shall apply for the purpose of this Service Contract.

  除非本合同另有规定,本条所使用的术语具有以下定义。

  (i) "Accepted Accounting Practices" shall mean accounting principles, practices and methods that are generally accepted and recognized in the international petroleum industry.

  “通用会计惯例”系指国际石油工业公认和认可的会计准则、会计实务和会计方法。

  (ii) "Affiliate" means any company or legal entity, which (i) controls either directly or indirectly Contractor, or (ii) which is controlled directly or ndirectly by Contractor, or (iii) is directly or indirectly controlled by a company or entity which directly or indirectly controls Contractor. "Control" means the right to xercise more than fifty percent (50%) of the voting rights in the appointment of the directors of such company or entity.

  “关联公司”系指任何一个具有下列条件之一的公司或法律实体:(i)直接或间接控制承包商,或(ii)被承包商直接或间接控制,或(iii)被承包商的公司或实体直接或间接控制。 “控制”系指对该公司或法律实体的董事的任命有50%以上的表决权。

  (iii) "Bank Charges" means the bank charges as defined in the Accounting Procedures “银行费用”系指会计程序中所规定的银行费用。

  (iv) "Barrel" means a volume of forty two (42) U.S. Gallons at sixty (60) degrees Fahrenheit and at normal atmospheric pressure.

  “桶”系指在 60华氏度和正常大气压条件下42美式加仑的`容积。

  (v) "Capital Costs" means all costs of Exploration Operations incurred by on tractor for carrying out the project until conclusion of Exploration Operations in accordance with the generally accepted principles commonly practiced in the

  international petroleum industry which shall include any and all cost incurred by Contractor except Non-Capital Costs.

  “资本成本”系指承包商依照国际石油工业界普遍采用和通行的规则实施勘探作业直至勘探作业结束,由承包商承担的除非资本成本以外所有勘探作业成本。

  (vi)"Commercial Field" means commercial field as described in Article 13 of this Service Contract.

  “商业价值油田”系指本合同第13条所述的具有商业价值的油田。

  (vii) "Condensate" means all liquid hydrocarbons, regardless of gravity, produced and recovered from the Contract Area as a liquid during all process necessary to reach the commercial specifications of Natural Gas.

  “凝析油”: 是指从合同区生产回收的,经过处理达到商业标准的所有液态烃,无论其密度如何。

  (viii) "Contract Area" means the area covered by this Service Contract, and described in Appendix A attached hereto and made a part hereof.

  “合同区域”是指本合同和作为本合同不可分割部分的附件A所描述的区域。

  (ix) "Contractor" means China Petrochemical Corporation, its legal successors, or any permitted assignee or assignees of any rights and obligations of Contractor. “承包商“系指中国石油化工集团公司及其合法承继者,或任何许可的可履行合同权利和义务的受让人。

  (x) "Controllable Material" means material which, in accordance with generally Accepted Accounting Practices, Contractor elects to record, control and inventory.

  A list of types of such material shall be furnished to N.I.O.C by Contractor within one month of the Effective Date.

  “可控制材料”系指按照公认的会计准则,承包商所记录、控制和库存的材料。这些材料的分类清单应在合同生效后一个月内提交N.I.O.C.。

  (xi) "Crude Oil" means all liquid hydrocarbons, regardless of gravity, including crude petroleum, produced and recovered from the Contract Area, as a liquid at atmospheric pressure fourteen and seven tenths (14. 7) pounds per square inch absolute and ambient temperature.

  “原油”是指所有液态烃 ,无论密度如何,包括合同区生产和回收的,在常温、常压(每平方英寸十四点七磅)下的液态油。

  (xii) "Cubic Meter" means one (1) cubic meter at sixty (60) degrees Fahrenheit and at normal atmospheric pressure.

  “立方米”指在正常大气压和60华氏度条件下的一立方米。

  (xiii) "Date of Commerciality" means the first day of the month following the date on which N.I.O.C approves that a Commercial Field has been established according to Article 23.

  “商业日期”系指N.I.O.C.依照第23条的规定批准有商业价值的油田建立的次月的第一天。

  (xiv) "Development Service Contract" means development service contract, model form which is attached hereto as Appendix E, that will be negotiated between Contractor and N.I.O.C in case of discovery of a Commercial Field.

  “开发服务合同”系指本合同附件E所列的文本,该合同将在发现有商业价值的油田,由承包商和NIOC协商。

  (xv) "Effective Date" means the date on which this Service Contract, being duly signed by the Parties is approved by the respective authorities.

  “生效日”系指当事人双方正式签订本合同后,获得各自权利(力)机构批准的日期。

  (xvi) "Exploration Expenditure(s)" means all expenditures made and paid by

  Contractor necessary to carry out the Exploration Operations covered by this Service Contract comprising Capital Costs and Non-Capital Costs, as determined in accordance with the Accounting Procedure.

  “勘探费用”系指承包商为实施本合同所述勘探作业按照会计程序所发生和支付的必要费用,包括资本成本和非资本成本。

  (xvii) "Exploration Operations" means all or any of the operations conducted by Contractor as authorized or envisaged under this Service Contract.

  “勘探作业”系指承包商执行的本合同项下的所有作业。

  (xviii) "Exploration Period" means the period of time as defined in Article 4 of this Contract.

  “勘探期”指本合同第4条所规定的期间。

  (xix) "Financial Year" means a Gregorian calendar year of twelve (12)

  consecutive months commencing on January 1st of each year respectively. The first financial year shall commence on the Effective Date of this Service Contract and end on 31st December of the same year.

  “财政年度”系指自公历1月1日起的十二个连续公历月。本合同的第一个财政年度应始于合同生效日止于当年的12月31日。

  (xx)"Land" means any land whether submerged or not.

  “土地”系指任何土地,包括被淹没或未淹没的土地。

  (xxi) "Material and Equipment" means Property, (with the exception of Land) including without limitation all facilities, supplies and equipment, acquired and held for use in Exploration Operations by the Contractor.

  “材料和设备”包括(土地除外)但不限于承包商为实施勘探作业获得和使用的所有设施、材料和设备。

  (xxii) "Natural Gas" means the gaseous affluent in its natural state including all of the liquefiable constituent thereof resulting from the production of Petroleum. “天然气”系指在石油开采过程中生产的、自然状态为气态的物质及其可液化成份。

  英文合同10

  本协议于_________年_________月_________日在中国_________由有关双方在平等互利基础上达成,按双方同意的下列条件发展业务关系:

  1.协议双方

  甲方:_________

  地址:_________

  电话:_________

  传真:_________

  乙方:_________

  地址:_________

  电话:_________

  传真:_________

  2.委任

  甲方指定乙方为其独家代理,为第三条所列商品从第四条所列区域的顾客中招揽订单,乙方接受上述委任。

  3.代理商品

  _________。

  4.代理区域

  仅限于_________

  5.最低业务量

  乙方同意,在本协议有效期内从上述代理区域内的顾客处招揽的上述商品的订单价值不低于_________美元。

  6.价格与支付

  每一笔交易的货物价格应由乙方与买主通过谈判确定,并须经甲方最后确认。

  付款使用保兑的、不可撤销的信用证,由买方开出,以甲方为受益人。信用证须在装运日期前15天到达甲方。

  7.独家代理权

  基于本协议授予的独家代理权,甲方不得直接或间接地通过乙方以外的渠道向_________顾客销售或出口第三条所列商品,乙方不得在_________经销、分销或促销与上述商品相竞争或类似的产品,也不得招揽或接受以到_________以外地区销售为目的的订单,在本协议有效期内,甲方应将其收到的来自_________其他商家的有关代理产品的询价或订单转交给乙方。

  8.商情报告

  为使甲方充分了解现行市场情况,乙方承担至少每季度一次或在必要时随时向甲方提供市场报告,内容包括与本协议代理商品的进口与销售有关的地方规章的变动、当地市场发展趋势以及买方对甲方按协议供应的货物的品质、包装、价格等方面的意见。乙方还承担向甲方提供其他供应商类似商品的报价和广告资料。

  9.广告及费用

  乙方负担本协议有效期内在新加坡销售代理商品做广告宣传的一切费用,并向甲方提交所用于广告的声像资料,供甲方事先核准。

  10.佣金

  对乙方直接获取并经甲方确认接受的订单,甲方按净发票售价向乙方支付5%的佣金。 佣金在甲方收到每笔订单的全部货款后才会支付。

  11.政府部门间的交易

  在甲、乙双方政府部门之间达成的交易不受本协议条款的限制,此类交易的金额也不应计入第五条规定的最低业务量。

  12.工业产权

  在本协议有效期内,为销售有关洗衣机,乙方可以使用甲方拥有的商标,并承认使用于或包含于_________中的'任何专利商标、版权或其他工业产权为甲方独家拥有。 一旦发现侵权,乙方应立即通知甲方并协助甲方采取措施保护甲方权益。

  13.协议有效期

  本协议经有关双方如期签署后生效,有效期为_________年,从_________年_________月_________日至_________年_________月_________日。除非作出相反通知,本协议期满后将延长_________个月。

  14.协议的终止

  在本协议有效期内,如果一方被发现违背协议条款,另一方有权终止协议。

  15.不可抗力

  由于水灾、火灾、地震、干旱、战争或协议一方无法预见、控制、避免和克服的其他事件导致不能或暂时不能全部或部分履行本协议,该方不负责任。但是,受不可抗力事件影响的一方须尽快将发生的事件通知另一方,并在不可抗力事件发生15天内将有关机构出具的不可抗力事件的证明寄交对方。

  16.仲裁

  因履行本协议所发生的一切争议应通过友好协商解决。如协商不能解决争议,则应将争议提交中国国际经济贸易仲裁委员会(北京),依据其仲裁规则进行仲裁。仲裁裁决是终局的,对双方都有约束力。

  甲方(签字):_________ 乙方(签字):_________

  附件:

  export exclusive agency agreement

  this agreement is made and entered into by and between the parties concerned on september _________,_________ in _________, china on the basis of equality and mutual benefit to develop business on terms and conditions mutually agreed upon as follow:

  1、the parties concerned

  party a: _________

  add: _________

  tel: _________

  fax:

  _________

  party b: _________

  add: _________

  tel: _________

  fax: _________

  2、appointment

  party a hereby appoints party b as its exclusive agent to solicit orders for the commodity stipulate in article 3 from customers in the territory stipulated in article 4,and party b accepts and assumes such appointment.

  3、commodity

  _________.

  4、territory

  in _________only

  5、minimum turnover

  party b shall undertake to solicit orders for the above commodity from customers in the above territory during the effective period of this agreement for not less than usd_________.

  6、price and payment

  the price for each individual transaction shall be fixed through negotiations between party b and the buyer, and subject to party as final confirmation.

  payment shall be made by confirmed, irrevocable l/c opened by the buyer in favor of party a ,which shall reach parth a 15 days before the date of shipment.

  7、exclusive right

  in consideration of the exclusive rights granted herein, party a shall not, directly or indirectly, sell or export the commodity stipulated in article 4 to customers in _________ through channels other than party b; party b shall not sell, distribute or promote the sales of any products competitive with or similar to the above commodity in _________ and shall not solicit or accept orders for the purpose of selling them outside _________. party a shall refer to party b any enquiries or orders for the commodity in question received by party a from other firms in _________ during the validity of this agreement.

  8、market report

  in order to keep party a well informed of the prevailing market conditions, party b should undertake to supply party a, at least once a quarter or at any time when necessary, with market reports concerning changes of the local regulations in connection with the import and sales of the commodity covered by this agreement, local market tendency and the buyers comments on quality, packing, price, etc.

  of the goods supplied by party a under this agreement. party b shall also supply party a with quotations and advertising materials on similar products of other suppliers.

  9、advertising and expenses

  party a shall bear all expenses for advertising and publicity in connection with the commodity in question in singapore within the validity of this agreement, and shall submit to party a all audio and video materials intended for advertising for prior approval.

  10、commission

  party a shall pay party b a commission of 5% on the net invoiced selling price on all orders directly obtained by party b and accepted by party a. no commission shall be paid until party a receives the full payment for each order.

  11、transactions between governmental bodies

  transactions concluded between govenmental bodies of party a and party b shall not be restricted by the terms and conditions of this agreement, nor shall the amount of such transactions be counted as part of the turnover stipulated in article 5.

  12、industrial property rights

  party b may use the trade-marks owned by party a for the sale of the _________ covered herein within the validity of this agreement, and shall acknowledge that all patents, trademarks, copy rights or any other industrial property rights used or embodied in the washing machines shall remain to be the sole properties of party a. should any infringement be found, party b shall promptly notify and assist party a to take steps to protect the latters rights.

  13、validity of agreement

  this agreement, when duly signed by the both parties concerned, shall remain if force for _________ months from october _________, _________ to _________ _________, and it shall be extended for another _________ months upon expiration unless notice in writing is given to the contrary.

  14、termination

  during the validity of this agreement, if either of the two parties is found to have violated the stipulations herein, the other party has the right to termi

  nate this agreement.

  15、force majeure

  either party shall not be held responsible for failure or delay to perform all or any part of this agreement due to flood, fire, earthquake, draught, war or any other events which could not be predicted, controlled, avoided or overcome by the relative party. however, the party affected by the event of force majeure shall inform the other party of its occurrence in writing as soon as possible and thereafter send a certificate of the event issued by the relevant authorities to the other party within 15 days after its occurrence.

  16、arbitration

  all disputes arising from the performance of this agreement shall be settled through friendly negotiation. should no settlement be reached throught negotiation, the case shallthen be submitted for arbitration to the china international economic and trade arbitration commission (beijing) and the rules of this commission shall be applied. the award of the arbitration shall be final and binding upon both parties.

  party a(signature) :_________ party b(signature):_________

  英文合同11

  【】FUND L.P.

  AND 【】INC.

  SERIES A PREFERRED STOCK FINANCING

  ___ ___, 20__

  This Term Sheet is not a legally binding agreement between the Investors and the Company, except the sections of “Confidentiality”, “Exclusivity” and “Administrative Fee”.

  Notwithstanding anything to the contrary, any obligations of the Investors to complete or provide funding for any transaction, whether contemplated herein or otherwise, are subject to the receipt of internal approvals, completion of due diligence to the satisfaction of the Investors in their sole and absolute discretion, and the parties having negotiated, approved, executed and delivered the appropriate definitive agreements. Until execution and delivery of such definitive agreements, the Investors shall have the absolute right to terminate all negotiations for any reason without liability.

  Exclusivity

  The Company agrees that within forty five (45) days from the date of the signing of this Term Sheet, the Company and its shareholders, board members, employees and their respective relatives or affiliates shall not, directly or indirectly, take any action to solicit or support any inquiry, proposal or offer form, furnish any information to or participate in any negotiations or discussions with, any third party, or enter into any

  agreement or arrangement, regarding any equity/debt funding or sale, without the prior written consent of the Investors.

  This exclusivity is automatically extended to the period necessary for the Company to satisfy the closing conditions outlined in the Stock Purchase Agreement section of this Term Sheet. Notwithstanding the

  foregoing, if neither the Company nor the Investors give written notice of its wish to terminate this Term Sheet at least five days prior to the end of the exclusivity period, the Term Sheet shall remain in full force and effect, and the Company shall continue to negotiate exclusively with the Investors until the Company or the Investors give written notice of termination.

  In this Term Sheet,

  "$" or "dollar" means United States dollars;

  "Ordinary Share Holders" mean the holders of Ordinary Shares;

  "Preferred Shares" mean shares of the Series A Preferred Stock; and

  "Shareholders" mean holders of Ordinary Shares and Preferred Shares.

  

  英文合同12

  销 售 合 同

  SALES CONTRACT

  编号:Contract No:日期: Date:

  签约地点:Signed at:

  卖方:Sellers:

  地址:Address:

  邮政编码:Postal Code:

  电话:Tel: 传真:Fax:

  买方:Buyers:

  地址:Address:

  邮政编码:Postal Code:

  电话:Tel: 传真:Fax:

  兹确认售予买方下列货品,其成交条款如下:

  The Seller hereby confirms selling the following goods on terms and conditions

  (3)公差:数量及总值均有_____%的增减,由卖方决定

  Tolerance: With _____% more or less both in amount and quantity allowed at the

  sellers option.

  (4) 原产地

  Country of Origin:

  (5) 付款方式:30%预付,70%发货前一周付清

  Payment terms: 30% deposit, 70% payment within one week before delivery.

  (6) 交货时间:收到预付款后15天内完成装运。

  Time of shipment: Within15 days after deposit received.

  (7) 贸易方式:FOBShanghai

  Terms of Shipment: FOBShanghai

  (8) 包装:胶合板木盘外封铁皮

  Packing: Plywood drum with steel sheet cover.

  (9) 保险:由卖方按发票全额110%投保至_____为止的_____险。

  Insurance: To be effected by seller for 110% of full invoice value covering _____ up to _____ only.

  (10) 装运口岸:中国上海港

  Port of Loading: Shanghai Port, China

  (11) 转运:允许

  Transshipment: Allowed

  (12) 分批装运:允许分批装运

  Partial Shipment: Allowed

  (13) 目的口岸:

  Port of Destination:

  (14) 唛头:Shipping Marks:

  (15) 单据:Documents:

  (16) 品质与数量、重量的异义与索赔:Quality/Quantity Discrepancy and Claim:

  (17) 逾期发运:如果由于买方原因造成逾期发运,买方承担责任。造成自签订合同之日起超过45天不能发运的,卖方将每日按货物金额的3%收取保管费;如果由于买方原因造成逾期发运超过6个月,卖方有权自行处置定金和货物。如果是卖方原因造成的逾期发运,卖方需提前告知买方并得到买方的确认并承担其他相关费用。

  LAST SHIPMENT: if the late delivery is caused by the buyer, the buyer shall bear the

  responsibility. If the delay has being made more than 45 days from the signing of the Sales Contract hereof, the buyer shall pay 3% of total amount each day, and if the delay is more than 6 months, the Seller has the right to dispose the down payment and the goods. If the late delivery is caused by the Seller, the Seller shall inform the Buyer in advance and get confirmation from the Buyer, and the related expense shall be born by the Seller.

  (18) 质量/数量异议:对于质量方面的异议,买方必须在货物抵达目的'港后30天之类提出:对于数量方面的异议,买方必须在货物抵达目的港后15天之内提出。对由于保险公司、运输公司、其他运输机构或邮局的原因所造成的货物差异,卖方不负任何责任。 QUALITY/QUANTITY DISCREPANCY: In case of quality discrepancy, claim shall be filed by the Buyer within 30 days after the arrival of the goods at port of destination; while for quantity discrepancy, claim shall be filed by the buyer within 15 days after the arrival of the goods at port of destination. It is understood that the Seller shall not be liable, for any discrepancy of goods shipped due to causes for which the Insurance Company, Shipping Company, other transportation organization or Post Office are liable.

  (19) 不可抗力:卖方对由于下列原因而导致不能或暂时不能履行全部或部分合同义务的,不负责任:水灾、火灾、地震、干旱、战争或其他任何在签约时卖方不能预料、无法控制且不能避免和克服的事件。但卖方因尽快地将所发生的事件通知对方,并应在事件发生后15天内将有关机构出具的不可抗力事件的证明寄交对方。如果不可抗力事件之影响超过120天,双方应协商合同继续履行或终止履行的事宜。

  FORCE MAJEURE: Seller shall not be responsible for failure or delay in performance of entire or portion of these Sale Contract obligations in consequence of Force Majeure incidents: flood, fire, earthquake, drought, war, or any other matters couldn’t be foreseen or controlled or couldn’t be avoided. But Seller shall inform the incidents to Buyer immediately, and shall delivery the certificate of Force Majeure incidents issued by related organization within 15 days after the incidents happened. If the incidents influence more than 120 days, both parties shall negotiate to decide whether to execute or terminate the Sales Contract.

  (20) 仲裁:因履行本合同所发生的一切争议,双方应友好协商解决,如协商仍不能解决争议,则应将争议提交中国国际经济贸易仲裁委员会(北京),依据其仲裁规则仲裁。仲裁裁决是终局的,对双方都有约束力。仲裁费应由败诉一方承担,但仲裁委员会另有裁定的除外。在仲裁期间,除仲裁部分之外的其他合同条款应继续执行。

  ARBITRATION: All disputes across from the execution of, or in connection with this Sales Contract shall be settled friendly through negotiation, in case no settlement can be reached, the case shall then be submitted to China International Economic and

  Trade Arbitration Commission, Beijing for arbitration in accordance with its provisional rules of procedure. The result of arbitration shall be born by the losing party except for the condition the Commission has other judgment. During the arbitration period, clauses beside of the arbitrated parts shall be executed.

  (21) 本合同为中英文对应,一式两份,买卖双方各执一份;合同自卖方签字盖章、买方签字后生效(传真件以及扫描具有正版相等法律效应)。

  The Sales Contract is concluded in Chinese and English with same effectiveness, and will come into effect on stamp of Seller and signing by Buyer. The Sales Contract is in dual original and each party shall have one original copy of this Sales Contract. (Any scanned and faxed copy shall have the same legal effect as the original one.)

  (22) 备注:Remark:

  买方确认签署: 卖方确认签署:

  For and on behalf of Buyer:For and on behalf of Seller:

  英文合同13

  甲方:party a: 乙方:party b:

  合同编号: contract no

  日期:date:

  签约地点:signed at:

  特约定:

  甲方基于下文所列各种因素,特与乙方达成了协议并一致同意:由甲方在订约日期之翌日起_____天之内为乙方建造并完成_____(涉约建筑)。涉约建筑之规模及所需的钢筋、水泥、砖块、石子和其它建筑材料之数量,均在作为合同附件的设计图和施工细则中予以说明。

  witnesses that the party a for considerations hereinafter named, contracts and agrees with the party b that party a will, within_____ days, next following the date hereof, build and finish a libarary building for party b. ( the building hereinafter is referred to as the said building.) the said building is of the following dimensions, with reinforced concrete, brick, stones and other materials, as are described in plans and specifications gereto annexed.

  基于上述情况,乙方及其法定代表郑重承诺向甲方支付人民币_____元整。支付方法商定如下:

  in consideration of the foregoing, party b shall, for itself and its legal representatives, promise to pay party a the sum of one million rmb yuan in manner as follows, to wit:

  在上述工程开工之日,支付人民币_____元整

  在_____年_____月_____日,支付人民币_____元整

  甲方:party a: 乙方:party b:

  合同编号: contract no

  日期:date:

  签约地点:signed at:

  英文合同14

  Individual Mortgage Loan Contract for Purchasing

  Commercial Housing

  Agricultural Bank of China

  GF Zi No.12105200500001133

  Guarantor: HUANG Wenya (sealed)

  In accordance with relevant state laws and rules, the contract is made after negotiations between the both parties.

  Loan items

  Article 1. Loan money:

  The debitor provides loan to the creditor to purchase the residential house. The contracted loaning amount: Article 2. Loan purpose:

  To purchase the housing locate The contract number of the debtor: Article 3. Loan period

  Article 4. Loan interests

  1. by the Bank of China. In the event that the Bank of China adjusts the interest rate of the loan, from Jan.1 the next year, the debtor performs the interest payment according to the new loans confirmed by the floating scope between the adjusted standard interest and the lending rate agreed in the contract. It will not notify the debtor, the guarantor and the mortgager again.

  2. If the borrower doesn’t refund the loan in accordance with the contract, from the overdue time, the lender has the right to call for additional money as penalty until the corpus and interests are paid off. Following the measure will be complied with. day

  3. The creditor has the right to call for percent raising money as penalty at the basis of the annual interest rate stipulated in the contract. In the event that the Bank of China adjusts the interest rate of the loan, the loan rate under the contract shall comply with the relevant regulation from the day of adjusting rate.

  4. If the borrower does not use the money according to the purpose stipulated in the contract, the lender has the right to call for percent raising money as penalty at the basis of the annual interest rate stipulated in the contract. In the event that the Bank of China adjusts the interest rate of the loan, the loan rate under the contract shall comply with the relevant regulation from the day of adjusting rate.

  Article 5.

  Under the circumstances that the following conditions are not achieved, the lender has the right not to provide the loan stipulated in the contract.

  1. The borrower shall offer relevant documents, materials and credence in accordance with the requirements of the lender. And the borrower shall

  handle the relevant procedures.

  2. The purchasing money of the first period and the money related to the contract have been paid off.

  3. If the contract has a guarantor and the procedures of relevant registration and/or insurance have been settled in accordance with the requirements of the borrower, this guarantee keeps effective.

  4. The borrower, the guarantor and the mortgager dont make any disadvantageous matters which will affect the safety of loan.

  Article 6. Transferring methods:

  The borrower opens an account in the lender’s bank. The account name is The opening bank iscard number is measure.

  1. The debtor irrevocably accredits the lender to transfer the money to the above settle account, then transfer to the house seller ), to pay the money agreed in the contract of purchasing house.

  2. The borrower irrevocably accredits the lender to transfer the money to ) (Account number),

  Article 7 Loan payment

  1. The borrower pays the principal and interest of the load under this of If there is not the day of borrowing, the payment day is the last day of every month. The borrower

  (1) Equal capital and interest payment.

  (2) Equal capital descending payment.

  (3)Other methods of payments

  2. If picking up the equal capital and interest payment, the borrower shall pay Article 8 Prepayment

  1. If Borrower needs to refund in advance, it shall note Lender one month before refund day and the notice is irrevocable upon delivery. On the precondition that the borrower promises to refund the money agreed in following item 2 due to breach of contract and the premises that the borrower abides by the prescription of prepayment, the lender may agree prepayment.

  2. If the borrower has prepayment days after the real day of loan lender in advance.

  Article 9 Change of payment time

  If the borrower wants to change the payment time, he shall submit a written application to the lender 30days in advance. After the approval of the guarantor and the mortgager, the borrower can sign the agreement of the changing of the limit time and handle relevant insurances and guarantee procedures.

  Article 10 Transfer of creditors rights and debt

  The borrower can transfer the rights and interests to the third party without the permission of the lender, guarantor and the mortgager.

  Article 11 Borrower’s declaration and guarantee

  Article 12

  Between the time of signing and the time of distributing money, if the borrower and the house seller have disputes about the rights and quality of the house, or it occurs some matters that may cause the borrower incapable of paying money, the lender has the right to terminate the contract.

  Guaranty of the Loan

  Article 13 Premises Guarantee

  The scope of mortgage is principal and interest of loan punished interest and the cost of real claims.

  Article 14 Mortgage Guarantee

  1. The mortgager voluntarily mortgager the following belongings The above guaranty is an integral part of the contract. moment.

  3. The scope of mortgage include the capital, the interest, the fine, compound interest, the money of breach of the contract, the compensation for damage of loan and all the fees that realize the creditor’s rights.

  4. The declaration and guarantee of the mortgager

  5. The efficacy of mortgage rights

  6. The control and management of the guaranty

  7. The insurance of the mortgage

  8. The registration of the mortgage

  9. The realization of the mortgage rights

  The duties of breach of the contract

  Article 15 Duties of the debtor

  When the Mortgager fails to pay the principal, interest and relevant expenses in full amount on time or fails to wholly perform its states or warranties under the contract, it will constitute a breach of contract. The mortgager shall pay the money of breach of the contract according to the quantity and the delaying days.

  英文合同15

  FOB CRUDE OIL SALES AGREEMENT

  离岸原油销售协议

  This is to confirm the Agreement between us as follow:

  我们之间的协议现来确认如下:

  Parties:

  当事人:

  SELLER- SAUDI ARABIAN OIL COMPANY, A COMPANY WITH LIMITED LIABILITY ORGANIZED UNDER THE LAWS OF THE KINGDOM OF SAUDI ARABIA

  卖方:沙特阿拉伯石油公司,一家依照阿拉伯法律下的有限责任公司。

  BUYER- A COMPANY INCORPORATED UNDER THE LAWS OF买方: 国家法律下的股份有限公司

  Term of Agreement

  合同条款

  This Agreement shall be effective as of and shall continue tin effect through and including with automatic one-year extensions thereafter unless terminated at the option of either party,other than for cause,upon at least sixty(60)days written notice prior to the expiration of the original term or,if applicable,any subsequent anniversary date.

  此合同自。。起开始生效。若双方未提出终止合同,该合同将自动延期一年。在终止期前至少60天开出书面证明原始条款有效,如果适用的话,其后任何年均可继续生效。

  Grade,Quantity and Quality:

  数量和质量等级

  3.1 Subject to availability and the production policies determined by the

  Government of the Kingdom of Saudi Arabia,SELLER shall deliver and sell to BUYER and BUYER shall lift or receive and buy from SELLER a total of { quantity in numbers and words}

  Barrels per day of Arabian Light crude oil, minus up to ten percent(10%)if BUYER s or SEELERs option,or plus up to ten percent (10%)if BUYER so requests and SELLER agrees. Additional volumes of crude oil of similar or different grades may be delivered under this agreement as the parties may from time to time agree.

  依据由沙特阿拉伯政府出台的有效相关产品政策,卖方应该将货物发送并卖给买家,买家也应该接受并且同意接手从卖方手里买的总数{插入数量的数字和文字}-------阿拉伯轻质原油,数量的上下幅度为总数量的10%。如果买家这样要求并且卖家同意的话。额外大量的原油同品级的或是不同品级的将会遵从买卖双方的意愿按照合同的要求发货。

  The availability of each grade of crude oil specified in Paragraph 3.1 will be advised by SELLER from time to time in accordance with the production policies of Government of the Kingdom of Saudi Arabia. Subject to availability, and underless otherwise mutually agreed, the quantitied of each grade of crude oil to be lifted or received and purchased by BUYER during the term of this Agreement shall be spread over the term of this Agreement as evenly as practicable.

  每个可用的原油等级的表述在条款3.1,根据沙特王国的生产政策通知给卖方。双方同意,每个品级的原油数量被买房收到和被购买的,在被协议期限之内,将会遍及又很轻的实用性的条款。

  Notwithstanding anything to the contrary contained else where in this Agreement and without prejudice to any other rights or remedies available to SELLER hereunder if at any time BUYER,for at any reason other than force majeure(as defined in Paragraph 11.6)or a reason attributable to SELLER, fails

  to lift or receive and purchase quantities of crude oil in accordance with this Paragraph 3, SELLER may at one time or from time to time thereafter, at its sole discretion, and upon notice to BUYER, reduce any or all quantities and grades of crude oil which BUYER would have otherwise been entitled to lift and buy.

  尽管任何相反的1包含在这个协议和其他地方不影响其他权利或补救措施提供本协议项下卖方有任何时候,如果买方在任何理由,不可抗力除外)项所定义的(11.6)或一个原因致使卖方不能提升,或接受和购买数量的原油依照本第三项规定,卖方可以在同一时间或从时间,以时间之后,行驶他的自由决定权,在通知买方,减少任何或全部数量、等级的原油,否则会被买方有权解除选购。

  The quality of each grade of crude oil delivered hereunder shall be the usual quality of that grade being made available by SELLER at the time of loading of the crude oil at the SELLERs loading port in Saudi Arabia. SELLER warrants that it has good and marketable title to the crude oil, free and clear of all charges, liens and encumbrances but THERE ARE NO GUARANTEES OR WARRANTIES, EXPRESS OR IMPLIED, OF MERCHANTABILITY, FITNESS OR SUITABILITY OF THE CRUDE OIL, FOR ANY PARTICULAR PURPOSE OR OTHERWISE, WHICH EXTEND BEYOND THE DESCRIPTION OF THE CRUDE OIL AND ANY SPECIFICATIONS THEREFOR CONTAINED IN THIS AGREEMENT.

  每个品级质量的原油是日常质量的,由卖方在装船原油卖方装运港美国在沙特的卖方的装运港。卖方保证具有良好的所有权与市场的原油、自由和明确的、留置物的所有指控,但没有及抵押担保或保证,明示或暗示,适销,或适度性的原油、适合于某特殊目的.性或其他的描述,超越了微生物对原油的任何规格因此包含在本协议。

  Price:

  4.1 The price per barrel of each grade of crude oil to be sold hereunder shall be the average of the means of Oman and Dubai crude oil quotations (as

  published in Platts Crude Oil Marketwire under the heading "Spot Assessment") for the entiremonth in which the Bill of Lading date falls, plus or minus a differential for each grade to be provided by SELLER to BUYER as per Paragraph 4.2.

  每个品级的原油的每桶价格买的价格将会取阿曼和迪拜的原油报价的均值的平均数。(正如在泼辣托市场上的点评估标题下的),一整个月的提单在日落期,加或减一个不同对于每个品级的由卖方提供给买方如段落4.2中的。

  On or before the fifth (5th) day of each month, SELLER shall notify BUYER of the differential to be used to determine the price per barrel of each grade of crude oil for sale under this Agreement during the following month ("Scheduled Month of Delivery"). Within five (5) calendar days after receipt of SELLERs notification as set forth in the preceding sentence, BUYER may elect to terminate this Agreement by delivering written notice thereof to SELLER. Unless BUYER elects to terminate this Agreement in accordance with the immediately preceding sentence, the price differential notified by SELLER shall apply. Termination by BUYER in accordance with this Paragraph 4.2 shall be effective as of the first day of the month following SELLERs receipt of BUYERs notice; provided, however, that termination under this or any other provision of this Agreement shall not affect the parties rights and obligations with respect to deliveries of crude oil under this Agreement which were made prior to the effective date of termination; and further provided that in the event of termination hereunder or expiration of the Agreement, this Agreement shall remain in effect with respect to all crude oil for which delivery has been confirmed pursuant to Paragraph 6. The differential applicable to such crude oil shall be the differential which was in effect during the month prior to termination.

  每个月第五天或是第五天之前,卖方需通知买方,习惯于决定每个品级的原油的每桶的价格在协议下的下一个月的销售(预订交货月)。在收到如前所

  述的内容卖方在五个日历天之内通知,买家可能选择终止合同,通过发送书面证明的方式由此发给卖方。除非买方根据前述的内容终止协议,通知卖方的价格差异将被申请。由买方根据段落4.2的终止将会有效,自当月的第一天起根据卖方收到买方的通知为准,假使,然而,在规定条款下的此终止将不会影响到当事人的权利和义务希望原油按照合同的要求运送,在生效期前终止;如果是,在有效期内终止合同,合同将保持有效考虑到原油的运送确定依照段落6.在终止期前一直有效。

  If delivery is at Yanbu, BUYER shall pay, in addition to the price calculated in accordance with Paragraph 4.1, the East-West Pipeline transit fee, currently U.S. $0.25 (twenty-five U.S. cents) per barrel.

  如果是在yanbu卸货,买家将会付款,额外价格的计算将会根据段落4.1,中东管道运输费,当前为每桶0.25美元(25美分)

  Should issuance of the Bill of Lading occur before or after the Scheduled Month of Delivery, the price of such cargo shall be calculated using the differential that would have applied had issuance of the Bill of Lading occurred in the Scheduled Month of Delivery; however, the Oman and Dubai Prices shall be calculated with reference to the Bill of Lading date, as set forth in Paragraph 4.1.

  签发提单应该在预期装运之前或是之后,运价将会计算使用不同的应该被申请的已经签发的提单;然而,阿曼和迪拜价格将会按照提单的日期来计算,如前所述的段落4.1

  Payment:

  支付条款;

  5.1 Payment for each parcel of crude oil sold shall be made in the full amount of SELLERs telexed or faxed invoice without discounts or deductions by BUYER to SELLER via electronic transfer in immediately available funds in U.S. Dollars to SELLERs account as follows:

  

  英文合同16


  The buyer: the seller: ____________ ____________

  Address: Address: ____________ ____________

  Tel: ____________ Tel: ____________

  Fax: Fax: ____________ ____________

  Contact: Contact: ____________ ____________

  The sale of the friendly negotiation of both parties, the buyer seller commissioned processing production ________ mould Co ______ set. The two sides reached the following processing agreement

  Basic mould of die:

  Product name serial number part name point number (mold type) mold single price (RMB yuan) delivery condition

  Total price: (including 17% VAT)

  The above set of mould material: _____________________

  (the above mold materials are provided by the seller).

  I. The rights and responsibilities of the two parties:

  Buyers responsibility and rights are as follows:

  1. the buyer is responsible for the delivery of the R & D requirements and plans of the sellers project, and provides the sales forecast as far as possible.

  2. the buyer is responsible for the delivery of the product design drawings and other related technical information required by the seller to the seller and the technical support.

  3., the buyer has the sole right to interpret the product design drawings and related technical data delivered to the seller. When there is ambiguity, the Seller shall consult the buyers opinion and confirm it by the buyer.

  4. after the seller completes the design and manufacture of the mould, the buyer will go to the sellers site to verify the mold, or to provide the product sample to the buyer for confirmation and confirmation by the seller. The moulds referred to in this contract include the mould of the product itself and the fixture and mould needed for the subsequent production.

  The rights and responsibilities of the seller are as follows:

  1. the seller is responsible for the design and manufacture of the moulds according to the product design drawings and other related technical information provided by the buyer.

  Be responsible for completing the mold according to the buyers design requirements in accordance with the stipulations of the contract.

  2. the Seller shall be responsible for providing timely certification and sample test, trial production of desired products. At the same time the seller must provide the details of the related products.

  The detailed test report is for the buyers confirmation. In case of repair / modification, the test report is also attached at the same time.

  The buyer does not bear any responsibility.

  1.5 the Seller shall give the buyer the corresponding compensation in the form of the buyers approval as the seller causes the buyer to spend the labor and cost outside the normal technical support as a result of the sellers cause.

  2. the progress of the model:

  2.1 the seller after the receipt of the buyer after the confirmation of product drawing, which began to enter the mold design and production stage, open cycle for ________ days

  2.2 due to buyers cause the delay of mold making progress is not calculated.

  2.3 if the sellers mold making process and other mistakes lead to the failure of the mold to be accepted and the buyer is in urgent need of production.

  At the same time, the production should be arranged with the existing mold, and the die should be reopened according to the requirements of the drawings and samples.

  3. mode of payment:

  Party B agrees that Party A will pay the payment as follows.

  3.1 separate settlement: Monthly knot, 60 days after the opening of the ticket, open 17% VAT invoices.

  3.1.1 of the total amount of the contract manufacturing batch mould (including VAT) for RMB _________ yuan (RMB ________ yuan), the buyer to pay the total amount of _____% mold, mold ___% residual cost allocation in the first 50K products, if the number of orders less than 50K, the buyer shall supply the seller after the unamortized tooling cost.

  3.1.2 from the two sides after the signing of the contract, the seller to provide value-added tax invoices (mold total ____%), the buyer within twenty working days of payment.

  4. product order: only after the quality acceptance of the product sample is qualified and the buyers written confirmation, the seller may accept the order of the third party authorized by the buyer or the buyer. The order contract signed by third parties authorized by the buyer with the buyers seller is subject to this contract.

  Four, product quality assurance

  After the seller has completed the mold, the Seller agrees to guarantee the quality of the product in accordance with the buyers quality standard (the first confirmation report).

  The buyer reserves the right to modify the content of the quality standard in accordance with the actual needs.

  Five. The ownership of the mold

  1. the ownership of all moulds and clamping fixtures and their assembly drawings and parts drawings (including 2D and 3D) involved in the contract shall be owned by the buyer, and the Seller shall not interfere with the buyers disposition of the molds. If the seller is responsible for the custody of the seller, the Seller shall not supply the mould to the third party without the buyers consent, otherwise the buyer shall have the right to ask the seller to return the mold fee and compensate for the loss.

  2. when the buyer pays the mold cost, the seller must cooperate with the buyer or the third party designated by the buyer to transfer the inspection and accept the replacement of the die from the sellers place, and will replace the worn parts at the expense of itself, so as to ensure the restart of production. The seller is obliged to assemble, rust and pack the moulds and send it to the place designated by the buyer. All mold assembly drawings and part drawings (including 2D and 3D) and all clamping devices must be transferred to the buyer at the same time.

  3., during the process of mold transfer, such as the improper assembly, rust prevention or packaging of the seller, it will cause damage to the mold, and all direct and indirect losses arising therefrom shall be borne by the seller.

  Six, mold maintenance

  1., the Seller guarantees the service life of the mould 500 thousand times, and the seller is responsible for free maintenance during this period. If the mold is not used during the service life, the Seller shall be responsible for changing or re opening the mold and taking the corresponding cost.

  2. the seller should die changes, maintenance and repairs in a timely manner and register, whether such a modification, maintenance and repair are

  The buyer made it. If the buyer is to ask the relevant technical details or evidence, the buyer may register with the time without notice. The Seller shall give the buyer a copy of the record once every three months. The seller should take the initiative to complete this task on a regular basis without the buyers request.

  Six. Intellectual property rights

  The product and the buyer 1. involved in this contract to provide design drawings and other information in the intellectual property is owned by the buyer, the buyer without permission, the Seller shall not disclose to any company or individual, otherwise all the losses resulting from the seller; the buyer only agreed to all data and information provided by the seller by the buyer the purpose of this contract based on the,

  2. the Seller agrees to the design drawings will not be provided by the buyer and other data or information for the purpose of non contract other than the seller or the buyer has the right to pursue responsibility; without written permission from the buyer, the Seller shall not in publications, advertising or other written and oral form to the seller to provide or have provided any data and information.

  3., without the buyers license, it is strictly prohibited for the seller to use this mould to supply other customers other than the buyer or the buyers designated customer, otherwise all direct and indirect losses arising from it shall be the sellers responsibility.

  4. other undisclosed matters of confidentiality are carried out in accordance with the "confidentiality agreement" signed by the buyer and the seller.

  Seven. Liability for breach of contract

  1. the Seller shall be liable for breach of contract if the seller fails to complete the mold making and sample delivery according to the progress of each stage specified in the 2.1. The Seller shall pay the buyer a fine of 2% of the total amount of this contract at a time of one day of delay. The amount of the penalty is not more than the total amount of the contract.

  2., if the sellers cause causes the sellers quality to be supplied to the buyer cant meet the buyers requirements, and the other materials will be lost and scrapped during the assembly process, the seller will fully compensate for the loss and scrap materials and the resulting artificial / stop line costs. The two parties may sign separately the raw material for production.

  3. the quality and progress of the product provided to the buyer by the seller for the sellers cause can not reach the buyer.

  Place)

  3. when the mold is certified by the buyer, the seller is responsible for the seal of the mold. If the buyer agrees that the seller is responsible for the subsequent processing and production of the products, the Seller shall be responsible for the repair and maintenance of the moulds, and the Seller shall make the batch production according to the order of the third party authorized by the buyer or the buyer.

  4. for all the molds produced by the buyer, the Seller shall provide the buyer with detailed design drawings. All drawings must be made in AutoCAD or pro-eng (pro-el2) and must be transmitted to the buyer in electronic form before the mold opening for approval.

  Two. Technical terms:

  1. repair and maintenance of the mold: the seller is responsible for the repair and maintenance of the mold during the production process.

  2., after no dispute between the two sides, the buyer will provide the product design drawings and related technical information to the seller, and send the engineer to the sellers technical exchange or the seller send the engineer to the buyer for technical communication. The product drawings and technical requirements list is attached to Annex 1.

  3. the seller promised to use the quality requirements of the mold for the system to produce products to the buyer

  4. the seller promised to use the mold for the system to produce the product can reach the sellers delivery capacity:

  Nissan energy: _______k, monthly capacity: ______k

  5. the seller promises that all the moulds involved in this contract can be reached to 400 thousand times.

  6., without the buyers permission, it is strictly prohibited for the seller to contract the whole part of the contract involved in the contract to other companies for processing. Otherwise, the Seller shall be liable for breach of contract in accordance with the breach clause of the contract as a breach of contract.

  Three. The terms of business:

  1. mold price:

  1.1 after negotiation between the two parties, the seller will provide the final offer of the mould approved by the buyer and sign the price confirmation as an indispensable part of the contract.

  The total amount of 1.2 contract (including VAT mold ____%) rmb_______.

  1.3 the total cost of the price of the mold contains the following expenses, and the Seller shall not ask the buyer for the following reasons:

  1.3.1 the cost of all the fixtures and tools required by the seller for the molding / two processing / assembly of the product;

  1.3.2 the seller, according to the contract, carries out the cost of material, equipment and manpower for mould design, test mould.

  1.3.3 the cost of the sample (800 sets) provided by the seller to the buyer for the certification of the mold and product;

  1.3.4 the seller is the cost of the die vulnerable spare parts to ensure the normal production of the mold;

  1.3.5 the cost of the related tools and tools for other processes that are prepared for the normal production of the product.

  1.4 when the written request of the buyer the seller according to the change of the product design for the mould modification, if the mould modification is relatively simple, including less mold material changes and other simple changes from the mold, the seller to the buyer without charges; if the modification is complex, great influence on the whole structure of the mold, then the seller according to the modified working hours for mold to the buyer by the buyer offer, the corresponding mold modification cost. The buyer shall not bear any responsibility for the repair or modification of the mold due to the sellers reason, due to the failure of the mold to meet the buyers requirements.

  1.5 by the seller to the buyers manual and cost technical support from the normal cost, the Seller shall give the buyer recognized the way the corresponding compensation.

  2. the progress of the model:

  2.1 after the seller has received the product drawing file after the buyers confirmation, that is,

  The cost of artificial / stop line formation. The two parties may sign separately the raw material for production.

  3. if the seller has caused the seller to the buyer of the product quality and schedule is not up to the requirements of the buyer, the buyer and customer missed the best time to market, or the buyer was forced to cancel the project, so that the buyer and its customers suffer serious losses and loss of material research, in addition to the seller to refund all previous the buyer to pay the purchase price, depending on the actual situation of the seller also bear the buyer direct and indirect economic losses.

  4., if the seller is unable to resist force, including the war, fire, strike, and other force majeure caused by Chinese law, the buyer will allow the buyer to dismiss it. The Seller shall notify the buyer in written form within 24 hours after the occurrence of the force majeure, and the seller is obliged to take all necessary measures to deliver the goods as soon as possible. If the force majeure continues for more than 2 weeks, the buyer has the right to cancel this contract.

  5. other unfinished matters: implemented in accordance with the economic contract law.

  Eight. Dispute settlement

  Any dispute arising from the execution of this contract shall be settled through friendly negotiation first. If no negotiation can be reached within 30 days, either party can submit the dispute to the municipal court.

  The parties to this contract shall be strictly enforced. If one party fails to perform the contract in the cause of the contract, the party must ask for the consent of the other party two weeks in advance, and the contract shall be terminated.

  The buyer: the seller: ____________ ____________

  Representative: Representative: ___________ ____________

  英文合同17

  The following document offers excellent guidelines when preparing a timber sale contract.?Separate articles may be added to suit specific circumstances.?It is advised that the Seller and Purchaser employ legal counsel to review the contract prior to its endorsement.

  Contract entered into this ______ day of _____, 20___., by and between __________ of _________ Illinois, hereinafter called the Seller, and _____________, of ____________(city), ___________(state), Illinois Timber Buyer License Number _______, hereinafter called the Purchaser, WITNESSETH:

  1. The Seller agrees to sell and the Purchaser agrees to buy for the total sum of ________dollars ($_______) under the conditions set forth in this contract all of the live standing timber marked or designated for cutting and all of the dead or down timber marked or designated upon an area of approximately _____ acres, situated in the _________ of Section ________, Twp._______ R._______, ____________ County, Illinois, on land owned and recorded in the name of _______________________.

  The Purchaser further agrees to pay to the Seller as an initial payment under this contract the sum of _________________ dollars ($_________), receipt of which is hereby acknowledged, and a final payment in the sum of ________________ dollars ($_______), prior to any cutting or removal of timber under this contract.

  2. The Seller further agrees to mark and dispose of the timber conveyed in this contract in strict accordance with the following conditions:

  (a) All trees to be included in this sale will be marked with a distinctive mark on the bole and stump of each tree.

  (b) No trees under _____ inches in diameter at a point 4 1/2 feet from the ground will be marked for cutting.

  (c) No concurrent contract involving the area or period covered in this contract has been or will be entered into by the Seller without the written consent of the Purchaser

  (d) The Purchaser and his employees shall have access to the area at all reasonable times and seasons for the purpose of carrying out the terms of this contract.

  (e) Unless otherwise specified, all material contained in the marked or designated trees is included in this sale

  (f)

  (g)

  3. The Purchaser further agrees to cut and remove all of the timber conveyed in this contract in strict accordance with the following conditions:

  (a) Unless an extension of time is agreed upon in writing between the Seller and Purchaser, all timber shall be paid for, cut, and removed on or before and none after the _____ day of _______, 20___, and any material not so removed shall revert to the Seller.

  (b) Unmarked trees and young timber shall be protected against unnecessary injury from felling and logging operations.?If, however, unmarked trees are cut, damages shall be paid the Seller at the rate of $1 per tree per M bd. ft. for all other species, and in the event that any such trees are cut, said trees shall remain upon the premises and shall be the property of the Seller.

  (c) Necessary logging roads shall be cleared by the Purchaser only after their locations have been definitely agreed upon with the Seller or his representative, and any trees to be removed in the clearing operations shall first be marked by the Seller.

  (d) During the life of this contract and on the area covered, care shall be exercised by the Purchaser and his employees against the starting and spread of fire, and they shall do all in their power to prevent and control fires.

  (e) Any liability for damage, destruction, or restoration of private or public improvements or personal damages occasioned by or in the exercise of this contract shall be the sole responsibility of the Purchaser, and the Purchaser shall save harmless the Seller on account of such damages.

  (f) The risk if loss or damage to the trees herein purchased, from any and all causes whatever, shall be borne by purchasers from the date hereof.

  (g) The Purchaser will not assign this agreement without the written consent of the Seller.

  (h)

  (g)

  (i)

  4. The Seller and Purchaser mutually agree as follows:

  (a) All modifications of the contract will be reduced to writing, dated, signed, and witnessed and attached to this contract.

  (b) Any need for reassignment of interest of either party may be changed within 10 days following written consent by both parties.?All terms of this contract legally bind the named representatives to excuse this document as written.

  (c) The total number of trees conveyed is _____ (having a volume of approximately _____bd. ft.) composed as follows:

  _______ white oak, _______ red and black oak, __________________, ____________________, ______________________, __________________.

  (d) In case of dispute over the terms of this contract, final decision shall rest with a reputable person to be mutually agreed upon the by parties to this contract.?If the parties hereto do not agree upon a third party within 10 days following the initiation of the dispute, or in the case of further disagreement, then within 15 days from the initiation of the dispute, it shall be submitted to a Board of Arbitration of three persons, one to be selected by each party to this contract and the third to be selected by the other two.?The Board shall decide the dispute within 5 days after the matter is referred to it.

  In the event that damages are awarded to the Seller by the Board of Arbitration and are not paid on the date that the award is made, then all operations of the Purchaser shall immediately cease, and if the award is not paid or satisfied within 30 days after the date of award, the Seller may take immediate possession of the premises upon which the timber is located, shall retain as liquidated damages all money paid by the Purchaser, and the title to all timber shall revert to and become the property of the seller.

  In witness whereof, the parties hereto have set their hands and seals this __________ day of ______________________ 20____.

  WITNESSES:

  ______________________________???______________________________

  for the Purchaser?? Purchaser

  ______________________________???______________________________

  for the Seller Seller

  英文合同18

  party a:party b:

  contract no

  date:

  signed at:

  witnesses that the party a for considerations hereinafter named, contracts and agrees with the party b that party a will, within_____ days, next following the date hereof, build and finish a libarary building for party b. ( the building hereinafter is referred to as the said building.) the said building is of the following dimensions, with reinforced concrete, brick, stones and other materials, as are described in plans and specifications gereto annexed.

  in consideration of the foregoing, party b shall, for itself and its legal representatives, promise to pay party a the sum of one million rmb yuan in manner as follows, to wit:

  rmb_____at the beginning of the said work.

  rmb_____on _____/ _____/_____( for example: 3/21/XX)

  rmb_____ on_____/ _____/_____

  rmb_____ on_____/ _____/_____

  rmb_____ on_____/ _____/_____

  and the remaining sum will be paid upon the completion of the work.

  it is further agreed that in order to be entitled to the said payments ( the first one excepted, which is otherwise secured ), party a or its legal representatives shall, according to the architects appraisement, have expended, in labor and material, the value of the payments already received by party a, on the building, at the time of payment.

  for failure to accomplish the faithful performance of the agreement aforesaid, the party so failing agrees to forfeit and pay to the other_____rmb yuan as fixed and settled damages, within one month form the time so failing.

  in witness whereof we have hereunto set our hands and seals the day and year first above written.

  signed, sealed and delivered

  in the presence of

  party a : party b:

  英文合同19

  有限公司(以下简称甲方)系外商投资经营企业,现聘用(以下简称乙方)为甲方合同制职工。根据《劳动法》和《上海市劳动合同条例》以下简称(条例),甲乙双方本着诚信、平等、协商的原则,一致同意签定本合同。

  (hereinafter referred to as “party A”) is a foreign- invested enterprise and employs xx hereinafter referred to as “party B”) as an employee by contract, according to the “labor law”and the “ordinance on shanghai labor contract”, (hereinafter referred to as “regulation”), both parties agree to sign the contract on the principle of good faith, equality and consultation.

  第一条合同期限

  article 1 term of the contract

  合同有效期限自___至___止,为期___年。其中___至___为试用期。

  The term of contract starts as from to ; totally one year(s). the probation period thereof is as from to .

  第二条工作岗位

  article 2 work position

  乙方应从事办公室经理工作。乙方将按照甲方的要求工作。其基本职责如下: (1)人力资源(2)自德国总部进口产品(3)日常办公室事务处理(4)观察收集市场信息(5)客户服务(6)会计相关信息支持(7)销售团队相关信息支持(8)仓库管理,包括货物和样品管理

  Party B shall engage office manager in. party B shall perform his duties according to instructions of party A. party B’s basic duties are detailed as follows: (1)labor management(2)import the products from German headquarter (3)manage the daily office routine (4)monitor and collect market information (5)customer service (6)support accountant with relevant information (7)support the sales team with relevant information (8)warehouse management ,including the goods and samples.

  2.甲方因工作安排需要和根据乙方的工作能力和工作表现,可随时更改乙方劳动报酬,但应在国家法律规定的范围内。

  According to the needs of work, the work ability and the work performance of party B, party A can change the income of party B at any time, but subject to the regulations made by the state.

  3.如果甲方认为乙方的工作能力和工作表现不符合本条第1款规定的工作要求,甲方有权在任何时候调换乙方的工作岗位、工作地点及劳动报酬,或解除本劳动合同。

  If party A thinks that party B’s work ability and work performance can not meet the requirements under item 1 of this article , party A has the right to change party B’s work position, the location of working, the income, or terminate the labor contract at any time.

  第三条工作条件和劳动保护

  article 3 working conditions and working protection

  甲方须为乙方提供符合国家规定的安全卫生的工作环境,并向乙方提供必要的劳动防护用品。

  Party A shall provide party B with the safe and healthful working environment and essential working protection according to the prc regulations.

  第四条工作时间

  article 4 working time

  1.乙方每天和每周工作时间参照甲方有关规定。

  The daily and the weekly working time refer to party A’s relative regulations.

  2.乙方享有国家规定的法定节假日、年假和其他法律法规和员工手册规定的假日。

  Party B is entitled to mandatory public holidays, the annual leave and other leaves according to laws and regulations and labor handbook.

  3.乙方为甲方工作满12个月后,乙方每年可享有10天带薪休假;工作满五年后每年享有15天带薪休假;满十年后每年享有20天带薪休假。乙方要休假时,应提前壹个月向甲方提出书面申请,得到甲方书面批准后,乙方才可休假。但员工每年可以享有最多五天的跨年度带薪休假。跨年度休假必须在第二年第一季度最后一天前休完。

  After working for party A for 12 months, party B is entitled to 10 days annual leave with full income each year. after working for party A for 5 years, party B is entitled to 15 days annual leave with full income each year. after working for party A for 10 years, party B is entitled to 20 days annual leave with full income each year. when party B wants to have a vacation, party B should provide an application in writing one month in advance. upon the written approval from party A, party B may have a vacation with full income. but party B may enjoy at most five days’ trans- year annual leaves that shall be completed by the last day of march in the next year.

  第五条劳动报酬

  article 5 compensation

  1.乙方收入参照本合同中附件1的规定。甲方实行新的工资制度时,乙方的工资待遇按新的制度予以调整。

  The income of party B is set out in appendix i of this contract. the income of party B will be adjusted accordingly when party A carries out a new income system.

  2.甲方实行年12个月薪金制,工作满一年后,每年十二月份发双薪。发薪日为第二个月的5号左右。甲方视乙方在服务的上一年中的表现和甲方的财务状况决定乙方是否享有年终奖金。乙方若在得到年终奖金后的六个月内辞职的,应在其离开公司前返还其全额年终奖金。 Party A carries out a system of 12 months’ income each year,after he or she have worked for one year,he or she can get the double salary in decmber of each year. the day of payment is about the 5th day of the next month. the annual bonus is subject to party A’s financial situation and party B’s work performance in the previous year. if party B resigns within 6 months after party B received the annual bonus for the previous year, party B shall refund this bonus back to party A before party B leaves the company.

  第六条劳动保险和福利待遇

  article 6 insurance and welfare

  乙方因生、老、病、伤、残、死,甲方按国家和地方有关规定办理。

  If party B gives birth, retires, falls in sickness, is injured, disabled, died, party A shall deal with it according to the national and local regulations relating to birth, pension, sickness, injure, disability and death.

  第七条劳动纪律及奖惩

  article 7 working regulations, reward and punishment

  1.乙方应遵守国家的法律法规,并遵守甲方的各项规章制度。

  Party B should abide by the law and regulations and the internal rules made by party A.

  2.乙方被依法追究刑事责任的,合同自动解除。

  this contract shall be terminated automatically if party B is accused by criminal charge.

  3.未经甲方书面同意,乙方不得在外兼职,也不能在任何情况下使用或准许他人使用其为甲方工作期间所获得的任何信息,包括但不限于,泄漏任何技术,市场或财务文件或信息给第三方。任意此类违反将被视为严重违反合同,一经发现,乙方应向甲方支付违约金50,000元人民币。如造成甲方的经济损失,乙方应当承担赔偿责任。

  Without the writing approval by party A, party B shall neither have a part time job outside at the same time nor in any form use or permit any person to use any information obtained during the period of its working for party A, including but not limited to, divulging or leaking any technical, market or financial documents or information to any third party. any disobey shall be considered as the serious breach of the contract. once found out, party B shall pay a penalty fee, amounting to 50,000 yuan to party A. if such breach causes the losses of party A, party B shall bear all liability for compensation.

  4.对于甲方为了业务需要给予乙方的预支款,一般情况下,乙方应在预支后的十个工作日内提供甲方要求的结算凭证,返还剩余预支款,与甲方完成结算;无论如何,该预支款应在预支后一个月内结算完毕。

  As to the advance granted by party A to party B for the business needs, in the normal case, party B shall provide invoices or bills for settlement required by party A, refund the remainder and complete the settlement with party A within ten working days from the date of the granting; in any event, such advance shall be settled in one month from the date of the granting.

  第八条合同的解除

  article 8 terminate of the contract

  1.符合下列情况之一(除了第四项),甲方可以无需事先通知乙方解除本合同:

  If any following situation (exclusive of item 4) occurs, party A has the right to terminate the contract without the notice in advance;

  (1)在试用期内,甲方可无条件辞退乙方;

  During the probation, party A may dismiss party B without any reason at any time;

  (2)甲方认为乙方因严重违反劳动纪律或规章制度的;

  Party A thinks that party B seriously violates the working discipline and stipulations;

  (3)乙方严重失职、营私舞弊、泄露重要商业信息;

  Party B has serious neglect of duty,jobbery or leak out of important business information;

  (4)甲方认为乙方工作表现及能力不能达到本合同第二条第一款的要求;

  Party A thinks that party B’s work performance and ability cannot meet the requirements under article 2 item 1 hereunder;

  (5)如果乙方严重违反最新<<员工手册>>及其他不时制定的规章制度。

  If party B seriously violates any rules or regulations set out in the latest version of “labor handbook” and internal rules stipulated from time to time.

  2.符合下列情况之一的,甲方不得解除本合同,但本合同第八条第一款规定和法律法规规定的情况除外。

  If any following situation occurs, party A has no right to terminate the contract, but except the situation set out in article 8 item 1 and laws and regulations.

  (1)乙方因病或非因工负伤在规定的.医疗期内。

  If party B is sick or injured, party A has no right to terminate the contract during the treatment or convalescence period.

  (2)实行计划生育的乙方(指女方)在孕期、产期和哺乳期间。

  During the period of the pregnant, giving birth and lactation of party B who abide by the birth control regulation of prc.

  3.乙方提出辞职的。应提前以书面形式向甲方提出申请。未经甲方书面批准,乙方不得辞职。甲方只有在每年下述两个时期对乙方辞职申请进行答复。该两个时期为每年五月至六月(针对去年十一月至当年四月提出的申请),十一月至十二月(针对当年五月至当年十月提出的申请)。在甲方批准乙方的辞职,乙方将工作项目与甲方交接后,并将所使用的所有仪器、工具以完好,清洁,功能正常的状态返还给甲方后,方可办理解除或终止合同的手续,但是前提是乙方还应自甲方接受其辞职后根据甲方要求,继续为甲方工作二个月,除非甲方放弃该权利。该二个月期满后,双方劳动关系最终解除或终止,乙方所享有的所有待遇如工资都即刻终止,其放弃提出任何经济要求。如果乙方不按照上述规定办理离职手续,在劳动关系正式解除前未经甲方同意即停止工作或不办理交接,即视乙方放弃所有根据法律和合同其享有的权利和待遇,如休假、任何补偿金等,甲方也不再对乙方负有任何责任,并有权追究其违约责任。

  If party B wants to resign, she should provide party A with a written application in advance. without the written approval, party B is not allowed to resign the job. party A only makes a reply in response to party B’s application of resignation during the following two periods, which is the period from may to june and the period from november to december each year, respectively. the reply during the period from may to jun each year is made for the application provided in the period from november last year to april this year. the reply during the period from november to december each year is made for the application provided in the period from may to october this year. after party A approves, in writing, the resignation, party B handed over the works it is responsible for to party A and delivered all working tools used by party B in complete, clean, and good condition back to party A, party B can be allowed to go through the procedure of terminating the contract, provided however that per requirements of party A, party B shall continue working for party A for two months as from the date of the acceptance by party A of his resignation, unless party A waives the right of such requirement. when such two months expires, the contract is formally terminated, any claim and right enjoyed or had by party B, such as income claims, shall be deemed as termination or expiration. party B gives up all rights of any claims against party A. if party B fails to handle the procedure of resignation stipulated above, stop working for party A or reject handing over his works to party A without the consent of party A before the formal termination of labor contract, such activities of party B shall be deemed as the waive of any right and claims party B enjoys or provides according to the labor contract and laws, such as holidays and severance payment in all kinds, and therefore party A has no any liability to party B and has the right to take action against it.

  4.甲乙双方任何一方提出解除合同,应提前壹个月书面通知对方(本合同第8.1和9.3条规定的情况除外)。该书面通知原则上应由双方签字。如接受通知一方不同意签字,则通知方可将该通知以挂号信的方式邮寄至下述对方地址即视为送达。但按照本合同第8.1条(1)、(2)、(3)、(5)项规定解除劳动合同的不必提前通知对方除外。

  If any party wants to terminate the labor contract, a written notice should be given to the other party 1 month in advance (exclusive of any one of article 8.1 and article 9.3). both parties should sign on this notice in principle. if the party receiving the notice is not willing to sign this notice, the notifying party shall post the notice by registered letter to the other party At the following address, which shall be deemed as delivery. according to any one of article 8. regulation 1. item (1),(2), (3),and (5),a written notice in advance is not required to be given by one party to the other party. party A’s address:

  第九条双方约定其他条款

  article 9 other provisions agreed by parties

  1.在合同期间,所有与甲方雇用有关或执行甲方的任务或者主要是利用甲方提供的条件所完成的发明创造和成绩,无论是通过脑力或体力,均属职务发明创造,归甲方所有,未经甲方批准不得以乙方名义申请专利,不得对外公开或交付其他方使用。

  All inventions and other achievements of party B whatever through intellectual as well as physical, which are made during and in connection with the employment at party A, or for completing the assignment of party A, or by the condition provided by party A, shall be deemed as employment invention and achievement and therefore belong to party A. without the approval by party A, party B shall not apply for patents and make it public and use it by other methods in the name of party B.

  2.对于甲方在本合同期内向乙方提供的培训,乙方应遵守甲方的培训规定,并不得向第三方泄露培训涉及的事宜.

  For each training provided by party A to party B during the term of the contract, party B shall follow the traininging instructions of party A strictly. any information provided relating to such training is not allowed to be disclosed to any third party.

  3.乙方掌握甲方生产技术,专利,经营等商业秘密的,其不得向任何第三方透露任何与上述有关的信息,即使在合同终止或解除后。如果乙方在要求解除劳动合同时,应提前6个月向甲方提出书面申请,以便甲方进行必要的岗位调整,乙方同意在该期间内的工资按照调整后的岗位工资标准计算。

  Where party B has access to technical, patent or management secrets, it is strictly forbidden for party B to leak out any of these information to any third party, even after termination of this contract. if party B wants to terminate this contract he should notify party A 6 months in advance with written resignation letter so that party A may move the position of party B. party B agrees that during said period, the income of party B is calculated according to the income standard for new position for party B.

  第十条违约责任

  article 10 breach liability

  1.乙方违反本合同第八条第3款和第4款规定的时限解除劳动合同,必须支付相当于乙方一个月收入的赔偿金。

  If party B violates the provisions relating to the time for terminating the contract prescribed in article 8. regulation 3 and 4 to terminate the contract, such party shall pay one-month income of party B to the other party As compensation.

  2.无论双方以任何形式解除劳动关系,乙方必须及时根据甲方的要求办理完整工作交接手续,否则甲方将要求乙方支付相当于乙方一个月收入乘以乙方在甲方工作年限数的赔偿金。 Party B shall completely hand over the job in time to party A no matter under which condition to terminating the contract, otherwise party B should pay party A a compensation, amounting to one month income of party B multiplying the amount of years party B has been working for party A.

  3.乙方如违反本合同第九条任意一款,乙方必须支付甲方至少50,000元人民币。

  If party B violates any regulation of article 9. party B shall pay at least 50,000 rmb a penalty to party A.

  第十一条劳动争议

  article 11 dispute

  本合同在上海签订.甲乙双方发生劳动争议时,由争议的一方或双方向上海市 区劳动争议仲裁委员会申请仲裁。

  this contract is signed by both parties in shanghai. if any dispute arises between party A and party B, the dispute can be solved by applying for arbitration with the district’s labor arbitration committee of shanghai.

  第十二条其他article 12 miscellaneous

  1.本合同一式二份,甲乙双方各执一份,经甲方法定代表人或授权人签字和乙方签字并加盖甲方公章后生效。两份合同具有同等的法律效力。双方间的劳动关系正式从乙方的招工录用手续办理完毕之日起开始计算。

  The contract is made in 2 originals, each party holding one. this contract becomes effective upon the execution of the legal representative of party A or authorized persons and party B, together with the company seal of party A. both originals have the same legal force. the labor relationship between both parties shall formally commerce as from the date of the completion of recruitment of party B.

  2.本合同签署后,乙方应配合甲方办理其招工录用手续。如因乙方个人原因导致招工录用手续无法及时办理完毕,乙方应承担由此引起的一切后果。

  After the execution of this contract, party B shall cooperate with party A to handle the procedure of recruitment. in the event that party B’s personal reason causes the failure of completion of such recruitment, party B shall bear all liability incurred.

  3.如果与合同条款有关的国家法律法规有所变更,该合同其他部份将继续有效。

  If any clause or regulation of this contract is or will become invalid due to the change of national laws and regulations, the rest of this contract will remain valid.

  4.甲方不时制定或修改的规章制度及《员工手册》是本合同的组成部分。

  The internal rules and employee handbook stipulated or modified by party A from time to time constitute a part of this contract.

  甲方: party A:代表: representative:盖章: stamp

  乙方party B:身份证号码

  2.合同附件

  (1) appendix no. 1

  1:乙方工资待遇1.乙方的税前月工资为:工资人民币___元,试用期内为人民币___元。甲方实行新的工资制度时,乙方的工资待遇按新的制度予以调整

  The monthly gross income structure of party B is like following. the basic income is rmb x in the probation and will be after it. party B’s income is subject to relevant policies and regulations of party A, which can be modified at any time.

  2.未经甲方书面批准,乙方不得以任何方式从公司客户处私自收取或扣留公司应收货款。一经发现,甲方有权立即要求乙方归还,及对乙方要求相当与乙方一个月收入的违约金。

  Without the written approval of party A, party B is not allowed to collect the money or keep the receivable in cash from the customers of party A in any kind of way. other wise party A has the right to ask party B give back immediately and the penalty amount one month income of party B.

  甲方:___

  party A:___

  代表:___

  representative (stamp):___

  乙方:___

  party B:___

  身份证号码:___

  id number:___

  3.补充协议

  (2) :保密协议

  appendix no.2 non-disclosure agreement of party B

  根据甲乙双方于20___年___11月___19日签订的劳动合同以下简称(合同),甲方聘请乙方担任甲方公司的办公室经理职务,鉴于乙方担任该职务将了解到甲方的商业秘密和技术秘密,经甲乙双方协商一致,双方就乙方在甲方任职期间以及离职后一定期间内保守甲方商业秘密和技术秘密事宜达成以下协议:

  According to the employment contract (hereinafter referred to as “contract”) made by both parties on nov. 19th, 20xx, party A employs party B as a position of office manager. considering that party B can have access to know-how and secret of party A’s commerce and technology during the term of employment (“know-how and secret”), through friendly consultation, for non-disclosure of party A’s know-how and secret during the term of employment and certain time after party B leaves party A, both parties hereby make the following contents:

  一、乙方在甲方任职期间,对其以任何方式获得的有关甲方的商业秘密和技术秘密,负有不向其他任何第三方泄露的义务。

  During the term of party B’s employment, party B shall be responsible for not disclosing, laying out to any third party know-how and secret which party B has access to in any way.

  二、如果由于甲方工作的需要,乙方必须向第三方提供与上述秘密有关的信息时,乙方应当事先向乙方的上司通报并获得书面许可后方可进行。

  In cases where, according to working needs of party A, party B has to provide a third party with said information in respect of know-how and secret, party B shall give a report to its supervisor and obtain a written consent before such provision of information.

  三、如果乙方因合同期满或其他原因致使其合同被解除而离开甲方,甲方可以在支付乙方竞业禁止补偿金人民币二万八千八百元整(28,800)元后,有权要求乙方在离职之日起两年内,不得为与甲方同行业的企业工作或提供任何服务,无论该企业注册或位于在何处。

  In the event that party B leaves party A upon the expiration of contract or the termination of the contract caused by any other reasons, after party A pays party B a compensation for non-competition, amounting to rmb 28,800, party A shall have the right to demand that party B shall not work for or provide any services to any enterprise in the same industry as party A’s for 2 years, wherever such enterprise is registered or located.

  四、如果乙方违反本协议第一、二条的规定,甲方有权要求乙方向甲方支付违约金人民币五万(50,000)元;如违反本协议第三条规定,乙方应向甲方支付违约金人民币十五万(150,000)元;除了上述违约金责任外,乙方应同时赔偿由于乙方的违约行为给甲方造成的一切经济损失,包括但不限于律师费用等。如乙方行为触犯我国刑法,除了上述民事责任外,乙方应承担相应的刑事责任。

  If party B breaches the stipulation set forth in article 1 and 2, party A has the right to require party B to pay a penalty fee, amounting to rmb50,000; if party B breaches the stipulation set forth in article 3, party B shall pay party A a penalty fee, amounting to rmb150,000; save the said liability for the payment of penalty fees, party B shall compensate party A all losses and damages incurred from activities of breach of party B, including but not limited to attorney fees etc. in the event that activities of party B breach the criminal law of china, save said civil liability, party B shall bear corresponding criminal liability.

  五、本协议中,(1)商业秘密和技术秘密是指:乙方在甲方任职期间所接触到的所有信息,包括但不限于,甲方原材料进货渠道、产品销售渠道、客户名单、合作伙伴信息、产品的成本、销售价格、生产工艺、生产设备等相关的信息,以及其它与甲方生产、经营、商业、技术、物流、财务、管理、采购、人事有关所有信息;(2)本协议所指上司是:xxx先生;(3)合同是指:以上提到的劳动合同以及该合同的修改、补充或延续。

  In this agreement, (1) know-how & secret refers to all information party B has access to during the term of employment with party A, including but not limit to party A’s raw materials outsourcing channels, products sale channels, information relating to cooperative partners, list of customers and clients, cost of products, sale price, and production techniques and procedure, manufacturing equipment, together with all information relating to party A production, management, commerce, technology, logistics, finance, operation, procurement and human resources; (2) the supervisor mentioned in this agreement is mr. xxx; (3) the contract means the above mentioned contract and all amendments, supplementary documents and renewing documents of the contract.

  六、乙方在此完全理解本协议第三条是否实施的决定权在于甲方;其次无论甲方是否执行第三条都不免除乙方在本协议项下其他义务的履行。

  Party B hereby fully understands that the decision on carrying out article 3 of this agreement shall be made by party A; secondly, whether or not to carry out such article shall not release any liability of party B under this agreement.

  七、本协议系合同的补充,如果本协议和合同的内容存在冲突,应以本协议为准,未尽事宜参照合同。

  This agreement is a supplement to the contract. if any discrepancy between this agreement and the contract exists in conflict, the agreement shall prevail. unmentioned matters in this agreement shall refer to the contract.

  八、本协议一式两份,甲乙双方各执一份,具有同等法律效力。

  This agreement is made in two originals, each one holding one with same effect.

  九、本协议自双方签字盖章后生效。

  The agreement shall become effective upon the signature and seal of both parties.

  甲方: ___

  party A:___

  代表:___

  representative:___

  乙方(签字):___

  party B:___

  签约日期:___

  date:___

  英文合同20

  合作协议书

  Cooperation Agreement

  合同编号:

  Contract No.:签订地点:西安

  Signing place of contract: Xi’an

  甲、乙双方本着互利互惠,诚实守信,优势互补的原则,经过友好协商,就甲方对于乙方生产太阳能电池组件中介合作事宜,达成如下协议:

  Party A and Party B agree to sign the cooperation contract on producing of solar panels, and that Party A introduces buyers for Party B, for mutual benefits in conditions as follows:

  1.合作内容

  Cooperative Content

  根据甲乙双方协商,达成以下合作内容:

  To conclude the below contents of cooperation according to negotiations between two parties:

  (1) 甲方介绍、协助和促成乙方与 签订生产 买卖合同;价格为,总价格为。

  Party A authorizes Party B to produce for .The unit price

  is, in sum .

  (2) 甲方应认真与其推荐的客户进行联络,介绍并推广乙方的产品,并为乙方与客户的沟通、谈判、商务运作等相关商务活动提供商业咨询服务,最终促成乙方与采购商签订买卖合同;

  On behalf of Party B, Party A is responsible to contact with, introduce Party Bs products to and operate related business activities with, promote signing contract between party B and.

  (3) 如果在采购合同执行过程中,由于甲方客户方面的不当,发生问题,在乙方的要求下,甲方有义务进行协调解决执行合同的问题;并要求甲方

  客户按采购合同及本合同条款执行。由于乙方的原因没有执行好合同条款的'情况下,那么甲方有权要求乙方按采购合同及本合同条款执行。

  In the process of execution purchase contract, when has

  undeserved problems, party A has duty to coordinate solving problems. When party B do not perform under the terms of contract well , Party A has right to require Party B executing terms of purchase contract.

  2.双方的责任、权利和义务

  Responsibilities, Rights and Obligations

  (1)甲方的责任、权利和义务

  Party As responsibility, rights and obligations:

  A. 甲方负责与其推荐的客户进行联络、介绍并推广乙方的产品,并协助乙方对客户的沟通、谈判、商务运作等相关商务活动,最终能达成乙方与

  采购商签订买卖合同;

  On behalf of Party B, Party A is responsible to contact with , introduce Party Bs products toand operate related business activities with ,promote signing contract between party B and .

  B. 如果在乙方签订的买卖合同执行过程中,由于甲方客户方面的原因而产生的问题,在乙方的要求下,甲方有义务进行协调解决执行合同的问题;

  由于乙方的原因而产生的问题,在甲方客户的要求下,甲方有义务进行

  协调解决执行合同的问题;

  In the process of execution purchase contract, when has undeserved problems, party A has duty to coordinate solving problems. When party B do not perform under the terms of contract well, Party A has right to require Party B executing terms of purchase contract.

  C. 乙方与客户的买卖合同签订后,按照其合同约定履行。任何一方出现违约行为,甲方应予以积极协调解决,但甲方不承担对任何一方的任何担

  保责任或其他法律责任,甲方有明确承诺的除外。

  After signing purchase contract, no matter party B or broken, Party A will coordinate solving problems. Except commitment, Party

  A will not have warranty and other legal responsibility for any one side.

  (2)乙方的责任、权利和义务

  Party Bs responsibilities, rights and obligations:

  乙方应保证生产太阳能电池组件的质量和功率数量,全部承担对于出现的产品质量和功率数量的责任;

  Party B should guarantee and be whole responsibility to quality and quantity of solar panels.

  3.费用与付款:

  Commission

  (1) 乙方提供甲方的咨询费,组件数量以乙方与签订的买卖合同为依据,以实际供货量为结算数量,共计。如果乙方供货量没有达到合

  同约定数量,乙方有权要求重新商定咨询费用;

  Party B pays Party A commission as , in sum, but the final commission amount will be subject to the actual quantity based on the sales contract. If the party B have not provided according to the sales contract, then the party B have right to re-negotiate the consulting fee.yiyi

  (2) 在乙方收到客户合同内规定的货柜的全款额后,通知甲方,甲方开具正规商业发票,乙方收到发票后15个工作日内支付相应货柜的咨询费。 Part B must inform Part A when receiving sum contract amount of specific container goods from the customer, and Part A should make out the standard commercial invoice. Part B must pay for the entire consulting fee of corresponding container after receiving the invoice within 15 working days.

  (3)若甲方未能促成 公司与乙方签署买卖合同,甲方无权要求乙方支付

  咨询费或者任何费用。咨询费用以实际发货量为准。

  If the Party A is unable to cause the signed contract between the Party

  B and company, the Party A is not entitled to claim any

  remuneration or fee.

  (4)甲方指定银行账户信息如下:

  Information of Party A designated bank account as below:

  4.违约责任

  Liability for Breach

  如果一方不能按照本协议执行而给另一方造成了损失,受害方有权利要求对方给予相应的赔偿。

  If any party is unable to perform this agreement and caused the loss of the other party, the victim has the right to ask for the corresponding compensation.

  5.转让和保密

  Assignment and confidentiality

  (1)未经过对方同意不得将本协议规定的责任、义务向第三方转让;

  Without the agreement of the other party, the responsibility and obligation of this cooperation agreement should not be transferred to third

  party.

  (2)合作项目的有关信息、各种资料文件和价格等,甲、乙双方应对第三方保密,不得以任何理由或方式泄密,因泄密造成的一切经济损失由泄密方负

【英文合同】相关文章:

英文销售合同11-22

英文合同模板集合八篇04-11

英文合同模板集锦5篇03-26

英文合同模板集锦五篇03-31

英文合同模板集合六篇03-30

英文合同模板集合6篇04-05

英文合同模板集锦9篇03-07

英文合同模板汇总8篇03-25

英文合同模板汇总7篇03-14

英文合同模板汇编10篇03-22